20150331 Q1_V2

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

 

FORM 10-Q

 

QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the quarterly period ended March 31, 2015

 

OR

 

TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the transition period from             to             

 

Commission File Number:  1-6314

 

Tutor Perini Corporation

(Exact name of registrant as specified in its charter)

 

 

 

 

MASSACHUSETTS

 

04-1717070

(State or other jurisdiction of
incorporation or organization)

 

(I.R.S. Employer
Identification No.)

 

15901 OLDEN STREET, SYLMAR, CALIFORNIA 91342-1093

(Address of principal executive offices)

(Zip code)

 

(818) 362-8391

(Registrant’s telephone number, including area code)

 

 

(Former name, former address and former fiscal year, if changed since last report)

 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes   No

 

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes   No 

 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer”, “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):

 

 

 

 

Large accelerated filer 

 

Accelerated filer 

 

 

 

Non-Accelerated filer 

 

Smaller reporting company 

 

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes   No 

 

The number of shares of common stock, $1.00 par value per share, of the registrant outstanding at May 1, 2015 was 49,001,429.

 

 

 

 

 

 


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

 

INDEX

 

 

 

 

 

 

 

 

Page Number

Part I. 

Financial Information:

 

 

Item 1.

Financial Statements (unaudited)

 

 

 

Consolidated Condensed Balance Sheets —  March 31, 2015 and December 31, 2014

3 - 4

 

 

Consolidated Condensed Statements of Operations — Three months ended March 31, 2015 and 2014

 

 

Consolidated Condensed Statements of Comprehensive Income — Three months ended March 31, 2015 and 2014

 

 

Consolidated Condensed Statement of Stockholders’ Equity Three months ended March 31, 2015

 

 

Consolidated Condensed Statements of Cash Flows — Three months ended March 31, 2015 and 2014

 

 

Notes to Consolidated Condensed Financial Statements

9 - 28

 

Item 2.

Management’s Discussion and Analysis of Financial Condition and Results of Operations

29 - 36

 

Item 3.

Quantitative and Qualitative Disclosures About Market Risk

36 

 

Item 4.

Controls and Procedures

36 

Part II. 

Other Information:

 

 

Item 1.

Legal Proceedings

36 

 

Item 1A.

Risk Factors

36 

 

Item 2.

Unregistered Sales of Equity Securities and Use of Proceeds

36 

 

Item 3.

Defaults Upon Senior Securities

36 

 

Item 4.

Mine Safety Disclosures

37 

 

Item 5.

Other Information

37 

 

Item 6.

Exhibits

38 

 

Signatures

 

39 

 

 

2


 

Table of Contents

 

Part I.  - Financial Information

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED BALANCE SHEETS

MARCH 31, 2015 AND DECEMBER 31, 2014

(Unaudited-in thousands, except share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

March 31, 2015

 

December 31, 2014

ASSETS

 

 

 

 

 

 

CURRENT ASSETS:

 

 

 

 

 

 

Cash and cash equivalents

 

$

145,958 

 

$

135,583 

Restricted cash

 

 

44,093 

 

 

44,370 

Accounts receivable, including retainage

 

 

1,394,120 

 

 

1,479,504 

Costs and estimated earnings in excess of billings

 

 

795,510 

 

 

726,402 

Deferred income taxes

 

 

17,962 

 

 

17,962 

Other current assets

 

 

74,367 

 

 

68,735 

Total current assets

 

 

2,472,010 

 

 

2,472,556 

 

 

 

 

 

 

 

PROPERTY AND EQUIPMENT (net of accumulated depreciation of $228,211 in 2015 and $220,028 in 2014)

 

 

523,622 

 

 

527,602 

 

 

 

 

 

 

 

OTHER ASSETS:

 

 

 

 

 

 

Goodwill

 

 

585,006 

 

 

585,006 

Intangible assets, net

 

 

99,311 

 

 

100,254 

Other

 

 

86,531 

 

 

87,897 

Total assets

 

$

3,766,480 

 

$

3,773,315 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

3


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED BALANCE SHEETS (continued)

MARCH 31, 2015 AND DECEMBER 31, 2014

(Unaudited-in thousands, except share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

March 31, 2015

 

December 31, 2014

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

CURRENT LIABILITIES:

 

 

 

 

 

 

Current maturities of long-term debt

 

$

87,600 

 

$

81,292 

Accounts payable, including retainage

 

 

802,191 

 

 

798,174 

Billings in excess of costs and estimated earnings

 

 

286,042 

 

 

319,296 

Accrued expenses and other current liabilities

 

 

152,916 

 

 

159,814 

Total current liabilities

 

 

1,328,749 

 

 

1,358,576 

 

 

 

 

 

 

 

LONG-TERM DEBT, less current maturities

 

 

795,742 

 

 

784,067 

 

 

 

 

 

 

 

DEFERRED INCOME TAXES

 

 

150,018 

 

 

150,371 

 

 

 

 

 

 

 

OTHER LONG-TERM LIABILITIES

 

 

113,507 

 

 

114,796 

Total liabilities

 

 

2,388,016 

 

 

2,407,810 

 

 

 

 

 

 

 

CONTINGENCIES AND COMMITMENTS

 

 

 

 

 

 

 

 

 

 

 

 

 

STOCKHOLDERS' EQUITY:

 

 

 

 

 

 

Preferred stock, $1 par value:

 

 

 

 

 

 

Authorized – 1,000,000 shares

 

 

 

 

 

 

Issued and outstanding – none

 

 

 —

 

 

 —

Common stock - $1 par value: 75,000,000 shares authorized; Shares issued and outstanding: 49,001,429 shares and 48,671,492 shares

 

 

49,001 

 

 

48,671 

Additional paid-in capital

 

 

1,033,997 

 

 

1,025,941 

Retained earnings

 

 

337,637 

 

 

332,511 

Accumulated other comprehensive loss

 

 

(42,171)

 

 

(41,618)

Total stockholders' equity

 

 

1,378,464 

 

 

1,365,505 

 

 

 

 

 

 

 

Total liabilities and stockholders' equity

 

$

3,766,480 

 

$

3,773,315 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

4


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF OPERATIONS

 (Unaudited-in thousands, except per share data)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

 

 

March 31,

 

 

 

2015

 

2014

 

 

 

 

 

 

 

 

Revenues

 

 

$

1,066,465 

 

$

955,233 

 

 

 

 

 

 

 

 

Cost of operations

 

 

 

975,706 

 

 

849,886 

 

 

 

 

 

 

 

 

Gross profit

 

 

 

90,759 

 

 

105,347 

 

 

 

 

 

 

 

 

General and administrative expenses

 

 

 

70,675 

 

 

63,850 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

 

 

20,084 

 

 

41,497 

 

 

 

 

 

 

 

 

Other (expense) income, net

 

 

 

(754)

 

 

(3,373)

Interest expense

 

 

 

(11,125)

 

 

(10,831)

 

 

 

 

 

 

 

 

Income before income taxes

 

 

 

8,205 

 

 

27,293 

 

 

 

 

 

 

 

 

Provision for income taxes

 

 

 

(3,079)

 

 

(11,354)

 

 

 

 

 

 

 

 

NET INCOME

 

 

$

5,126 

 

$

15,939 

 

 

 

 

 

 

 

 

BASIC EARNINGS PER COMMON SHARE

 

 

$

0.11 

 

$

0.33 

 

 

 

 

 

 

 

 

DILUTED EARNINGS PER COMMON SHARE

 

 

$

0.10 

 

$

0.33 

 

 

 

 

 

 

 

 

WEIGHTED AVERAGE COMMON SHARES OUTSTANDING:

 

 

 

 

 

 

 

BASIC

 

 

 

48,747 

 

 

48,440 

Effect of dilutive stock options and restricted stock units

 

 

 

796 

 

 

490 

DILUTED

 

 

 

49,543 

 

 

48,930 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

5


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF COMPREHENSIVE INCOME

(Unaudited-in thousands) 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

 

March 31,

 

 

2015

 

2014

 

 

 

 

 

 

 

NET INCOME

 

$

5,126 

 

$

15,939 

 

 

 

 

 

 

 

OTHER COMPREHENSIVE INCOME (LOSS):

 

 

 

 

 

 

  Foreign currency translation

 

 

(964)

 

 

(490)

  Change in fair value of investments

 

 

(16)

 

 

188 

  Change in fair value of interest rate swap

 

 

74 

 

 

138 

Other comprehensive income before taxes

 

 

(906)

 

 

(164)

INCOME TAX EXPENSE (BENEFIT):

 

 

 

 

 

 

  Foreign currency translation

 

 

(376)

 

 

(204)

  Change in fair value of investments

 

 

(6)

 

 

  Change in fair value of interest rate swap

 

 

29 

 

 

57 

Income tax expense

 

 

(353)

 

 

(140)

NET OTHER COMPREHENSIVE INCOME (LOSS)

 

 

(553)

 

 

(24)

 

 

 

 

 

 

 

TOTAL COMPREHENSIVE INCOME

 

$

4,573 

 

$

15,915 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

6


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENT OF STOCKHOLDERS’ EQUITY

FOR THE THREE MONTHS ENDED MARCH 31, 2015

(Unaudited-in thousands) 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Accumulated

 

 

 

 

 

 

 

 

Additional

 

 

 

 

Other

 

 

 

 

 

Common

 

Paid-in

 

Retained

 

Comprehensive

 

 

 

 

 

Stock

 

Capital

 

Earnings

 

(Loss) Income

 

Total

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balance - December 31, 2014

 

$

48,671 

 

$

1,025,941 

 

$

332,511 

 

$

(41,618)

 

$

1,365,505 

Net income

 

 

 —

 

 

 —

 

 

5,126 

 

 

 —

 

 

5,126 

Other comprehensive income/(loss)

 

 

 —

 

 

 —

 

 

 —

 

 

(553)

 

 

(553)

Total comprehensive income

 

 

 

 

 

 

 

 

 

 

 

 

 

 

4,573 

Stock-based compensation expense

 

 

 —

 

 

9,159 

 

 

 —

 

 

 —

 

 

9,159 

Issuance of common stock, net

 

 

330 

 

 

(1,103)

 

 

 —

 

 

 —

 

 

(773)

Balance - March 31, 2015

 

$

49,001 

 

$

1,033,997 

 

$

337,637 

 

$

(42,171)

 

$

1,378,464 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

7


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED CONDENSED STATEMENTS OF CASH FLOWS

(UNAUDITED)

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

THREE MONTHS ENDED MARCH 31,

 

 

2015

 

2014

Cash Flows from Operating Activities:

 

 

 

 

 

 

Net income

 

$

5,126 

 

$

15,939 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

 

Depreciation and amortization

 

 

10,594 

 

 

14,659 

Stock-based compensation expense

 

 

9,159 

 

 

5,429 

Deferred income taxes

 

 

 —

 

 

45 

(Gain) loss on sale of property and equipment

 

 

(276)

 

 

427 

Other long-term liabilities

 

 

2,381 

 

 

3,494 

Other non-cash items

 

 

(2,227)

 

 

(427)

Changes in other components of working capital 

 

 

(27,081)

 

 

(80,696)

NET CASH USED IN OPERATING ACTIVITIES

 

 

(2,324)

 

 

(41,130)

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

Acquisition of property and equipment excluding certain financed purchases

 

 

(5,691)

 

 

(8,352)

Proceeds from sale of property and equipment

 

 

798 

 

 

1,417 

Change in restricted cash

 

 

277 

 

 

(675)

NET CASH USED BY INVESTING ACTIVITIES

 

 

(4,616)

 

 

(7,610)

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

Proceeds from debt

 

 

280,200 

 

 

178,038 

Repayment of debt

 

 

(262,112)

 

 

(113,551)

Business acquisition-related payments

 

 

 —

 

 

(1,031)

Issuance of common stock and effect of cashless exercise

 

 

(773)

 

 

(1,575)

NET CASH PROVIDED BY FINANCING ACTIVITIES

 

 

17,315 

 

 

61,881 

 

 

 

 

 

 

 

Net Increase in Cash and Cash Equivalents

 

 

10,375 

 

 

13,141 

Cash and Cash Equivalents at Beginning of Year

 

 

135,583 

 

 

119,923 

Cash and Cash Equivalents at End of Period

 

$

145,958 

 

$

133,064 

 

 

 

 

 

 

 

Supplemental Disclosure of Cash Paid For:

 

 

 

 

 

 

Interest

 

 

7,616 

 

 

5,383 

Income taxes

 

$

8,057 

 

$

11,703 

Supplemental Disclosure of Non-cash Transactions:

 

 

 

 

 

 

Property and equipment acquired through financing arrangements not included above

 

 

 —

 

 

22,332 

 

The accompanying notes are an integral part of these consolidated condensed financial statements.

 

8


 

Table of Contents

 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED CONDENSED FINANCIAL STATEMENTS

 

(1)     Basis of Presentation

 

The unaudited consolidated condensed financial statements presented herein include the accounts of Tutor Perini Corporation and its wholly owned subsidiaries (“Tutor Perini” or the “Company”). The Company’s interests in construction joint ventures are accounted for using the proportionate consolidation method whereby the Company’s proportionate share of each joint venture’s assets, liabilities, revenues and cost of operations are included in the appropriate classifications in the consolidated financial statements. All intercompany transactions and balances have been eliminated in consolidation.

 

The unaudited consolidated condensed financial statements have been prepared in accordance with the instructions to Form 10-Q and do not include all of the information and note disclosures required by accounting principles generally accepted in the United States as codified in the Financial Accounting Standards Board’s (“FASB”) Accounting Standards Codification. These statements should be read in conjunction with the financial statements and notes thereto included in the Company’s Annual Report on Form 10-K for the year ended December 31, 2014.

 

In the opinion of management, the accompanying unaudited consolidated condensed financial statements include all adjustments, consisting only of normal recurring adjustments necessary to present fairly the Company’s financial position as of March 31, 2015 and December 31, 2014, results of operations and comprehensive income, for the three months ended March 31, 2015 and 2014, and cash flows for the three months ended March 31, 2015 and 2014. The results of the three months ended March 31, 2015 are not indicative of the results that may be expected for the year ending December 31, 2015 because, among other reasons, such results can vary depending on the timing of progress achieved and changes in estimated profitability of projects being reported.

 

The Company considers events or transactions that occur after the balance sheet date but before the financial statements are issued to provide additional evidence relative to certain estimates or to identify matters that require additional disclosures.

 

(2)     Significant Accounting Policies

 

The significant accounting policies followed by the Company and its subsidiaries in preparing its consolidated financial statements are set forth in Note 1 to the financial statements included in the Company’s Annual Report on Form 10-K for the year ended December 31, 2014.

 

Recently Issued Accounting Pronouncements

 

In May 2014, the FASB issued Accounting Standards Update (“ASU”) ASU No. 2014-09, Revenue from Contracts with Customers (Topic 606), which supersedes the revenue recognition requirements in ASC 605, Revenue Recognition. This ASU addresses when an entity should recognize revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the entity expects to be entitled in exchange for those goods or services. This ASU is effective for annual reporting periods beginning after December 15, 2016, including interim periods within that reporting period, using one of two retrospective application methods. Early application is not permitted. In April 2015, FASB proposed to defer the effective date of the ASU to annual reporting periods beginning after December 15, 2017, including interim periods within that reporting period. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

 

In June 2014, the FASB issued ASU No. 2014-12, Compensation — Stock Compensation (Topic 718): Accounting for Share-Based Payments When the Terms of an Award Provide That a Performance Target Could Be Achieved after the Requisite Service Period, clarifying the recognition timing of expense associated with certain performance based stock awards when the performance target that affects vesting could be achieved after the requisite service period. This ASU is an update to FASB ASC Topic 718 and is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015 with earlier adoption permitted. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements.

 

In February 2015, the FASB issued ASU No. 2015-02, Consolidation (Topic 810). The goal of this ASU is to reduce the potentially distortive impact on reporting entities’ consolidated financial statements resulting from the consolidation of certain legal entities, including joint ventures and variable interest entities. This ASU is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements. 

In April 2015, the FASB issued ASU 2015-03, Interest – Imputation of Interest (Subtopic 835-30). This ASU requires that debt issuance costs related to a recognized debt liability be presented in the balance sheet as a direct deduction from the carrying amount of that debt liability, consistent with debt discounts. This ASU is effective for fiscal years, and interim periods within those years,

9


 

Table of Contents

 

beginning after December 15, 2015. The adoption of this ASU is not expected to have a material impact on the Company’s financial statements. 

Use of and Changes in Estimates

 

The Company’s construction business involves making significant estimates and assumptions in the normal course of business relating to its contracts and its joint venture contracts. Management focuses on evaluating the performance of contracts individually. These estimates can vary in the normal course of business as projects progress, when estimated productivity assumptions change based on experience to date and uncertainties are resolved. Change orders and claims, as well as changes in related estimates of costs to complete, are considered revisions in estimates. The Company uses the cumulative catch-up method applicable to construction contract accounting to account for revisions in estimates. The impact on operating margin in a reporting period and future periods from a change in estimate will depend on the stage of contract completion.

 

There were no significant changes in contract estimates at completion that impacted gross profit for the three months ended March 31, 2015 and 2014.

 

(3)     Cash and Cash Equivalents and Restricted Cash

 

Cash and cash equivalents include short-term, highly liquid investments with original maturities of three months or less when acquired.

 

Cash and cash equivalents, as reported in the accompanying Consolidated Condensed Balance Sheets, consist of amounts held by the Company that are available for general corporate purposes and the Company’s proportionate share of amounts held by construction joint ventures that are available only for joint venture-related uses, including future distributions to joint venture partners. Restricted cash is primarily held to secure insurance-related contingent obligations, such as insurance claim deductibles, in lieu of letters of credit.

 

Cash and cash equivalents and restricted cash consisted of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

March 31,

 

December 31,

 

 

2015

 

2014

 

 

(in thousands)

Corporate cash and cash equivalents (available for general corporate purposes)

 

$

61,903 

 

$

40,846 

Company's share of joint venture cash and cash equivalents (available only for joint venture purposes, including future distributions)

 

 

84,055 

 

 

94,737 

Total Cash and Cash Equivalents

 

$

145,958 

 

$

135,583 

 

 

 

 

 

 

 

Restricted Cash

 

$

44,093 

 

$

44,370 

 

 

 

 

 

 

 

(4)     Costs and estimated earnings in excess of billings

 

Costs and estimated earnings in excess of billings related to the Company’s contracts and joint venture contracts consisted of the following:

 

 

 

 

 

 

 

 

 

 

 

March 31,

 

December 31,

 

 

2015

 

2014

 

 

(in thousands)

Unbilled costs and profits incurred to date*

 

$

241,631 

 

$

253,078 

Unapproved change orders

 

 

235,242 

 

 

161,375 

Claims

 

 

318,637 

 

 

311,949 

 

 

$

795,510 

 

$

726,402 

 

10


 

Table of Contents

 


* Represents the excess of contract costs and profits recognized to date on the percentage of completion accounting method over the amount of contract billings to date on certain contracts.

 

Of the balance of “Unapproved change orders” and “Claims” included above in costs and estimated earnings in excess of billings at March 31, 2015 and December 31, 2014, approximately $43.4 million and $38.4 million, respectively, are the amounts subject to pending litigation or dispute resolution proceedings as described in Note 7 — Contingencies and Commitments. These amounts are management’s estimate of the probable cost recovery from the disputed claims considering such factors as evaluation of entitlement, settlements reached to date and experience with the customer. In the event that future facts and circumstances, including the resolution of disputed claims, cause a reduction in the aggregate amount of the estimated probable cost recovery from the disputed claims, the amount of such reduction will be recorded against earnings in the relevant future period.

 

The prerequisite for billing “Unbilled costs and profits incurred to date” is provided in the defined billing terms of each of the applicable contracts. The prerequisite for billing “Unapproved change orders” or “Claims” is the final resolution and agreement between the parties.

 

(5)     Fair Value Measurements

 

The Company measures certain financial instruments, including cash and cash equivalents, such as money market funds, at fair value. The fair values were determined based on a three-tier valuation hierarchy for disclosure of significant inputs. These hierarchical tiers are defined as follows:

 

Level 1 — inputs are unadjusted quoted prices in active markets for identical assets or liabilities.

 

Level 2 — inputs are other than quoted prices in active markets that are either directly or indirectly observable through market corroboration.

 

Level 3 — inputs are unobservable inputs in which little or no market data exists, therefore requiring an entity to develop its own assumptions based on the best information available in the circumstances.

 

The carrying amount of cash and cash equivalents approximates fair value due to the short-term nature of these items. The carrying value of receivables, payables and other amounts arising out of normal contract activities, including retainage, which may be settled beyond one year, is estimated to approximate fair value. Of the Company’s long-term debt, the fair values of the fixed rate senior unsecured notes as of March 31, 2015 and December 31, 2014 were $312.0 million and $310.3 million, respectively, compared to the carrying value of $298.8 million as of both March 31, 2015 and December 31, 2014. The fair value of the senior unsecured notes was estimated using Level 1 inputs based on market quotations including broker quotes or interest rates for the same financial instruments at March 31, 2015 and December 31, 2014. The carrying values of the remaining balance of the Company’s long-term debt of $584.5 million and $566.6 million at March 31, 2015 and December 31, 2014, respectively, were estimated to approximate their fair values.

 

The following is a summary of financial statement items carried at estimated fair values measured on a recurring basis as of the dates presented:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Fair Value Measurements Using

 

 

 

 

 

 

 

 

 

Significant

 

 

 

 

 

 

 

 

 

Quoted prices

 

 

other

 

 

Significant

 

 

 

Total

 

 

in active

 

 

observable

 

 

unobservable

 

 

 

Carrying

 

 

markets

 

 

inputs

 

 

inputs

At March 31, 2015

 

 

Value

 

 

(Level 1)

 

 

(Level 2)

 

 

(Level 3)

 

 

(in thousands)

Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 Cash and cash equivalents (1)

 

$

145,958 

 

$

145,958 

 

$

 —

 

$

 —

 Restricted cash (1)

 

 

44,093 

 

 

44,093 

 

 

 —

 

 

 —

 Investments in lieu of retainage (2)

 

 

31,425 

 

 

22,670 

 

 

8,755 

 

 

 —

Total

 

$

221,476 

 

$

212,721 

 

$

8,755 

 

$

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

Liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

 Interest rate swap contract (3)

 

$

305 

 

$

 —

 

$

305 

 

$

 —

 Contingent consideration (4)

 

 

25,560 

 

 

 —

 

 

 —

 

 

25,560 

 

 

$

25,865 

 

$

 —

 

$

305 

 

$

25,560 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

11


 

Table of Contents

 

 

 

 

 

 

Fair Value Measurements Using

 

 

 

 

 

 

 

 

 

Significant

 

 

 

 

 

 

 

 

 

Quoted prices

 

 

other

 

 

Significant

 

 

 

Total

 

 

in active

 

 

observable

 

 

unobservable

 

 

 

Carrying

 

 

markets

 

 

inputs

 

 

inputs

At December 31, 2014

 

 

Value

 

 

(Level 1)

 

 

(Level 2)

 

 

(Level 3)

 

 

(in thousands)

Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 Cash and cash equivalents (1)

 

$

135,583 

 

$

135,583 

 

$

 —

 

$

 —

 Restricted cash (1)

 

 

44,370 

 

 

44,370 

 

 

 —

 

 

 —

Investments in lieu of retainage (2)

 

 

33,224 

 

 

25,761 

 

 

7,463 

 

 

 —

Total

 

$

213,177 

 

$

205,714 

 

$

7,463 

 

$

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

Liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

 Interest rate swap contract (3)

 

$

381 

 

$

 —

 

$

381 

 

$

 —

 Contingent consideration (4)

 

 

24,814 

 

 

 —

 

 

 —

 

 

24,814 

 

 

$

25,195 

 

$

 —

 

$

381 

 

$

24,814 

 

 

 

 


(1)

Cash, cash equivalents and restricted cash consist primarily of money market funds with original maturity dates of three months or less, for which fair value is determined through quoted market prices.

(2)

Investments in lieu of retainage are classified as account receivables, including retainage and are comprised primarily of money market funds for which fair value is determined through quoted market prices. Investment in lieu of retainage also includes U.S. Treasury Notes and other municipal bonds for which fair value is determined through quoted market prices and other similar high quality investments whose values are determined from readily-available pricing sources for comparable instruments.

(3)

As discussed in Note 10 — Financial Commitments, the Company entered into a swap agreement with Bank of America, N.A. to establish a long-term interest rate for its former $200 million five-year term loan. The swap agreement became effective for the term loan principal balance outstanding at January 31, 2012. This term loan was paid off and the then current amount refinanced on June 5, 2014, providing for a $250 million term loan maturing on June 5, 2019. The interest rate swap continues on its original basis for the initial term and amount and finalizes on June 30, 2016. Bank of America calculates the fair market value of the interest rate swap liability by utilizing a mark-to-market valuation model that is based on current observable interest rates, expected future interest rates and the Company’s credit risk. The Company reviews the mark-to-market valuation when determining the fair value of the interest rate swap liability to be recognized. This liability is classified as a component of other long-term liabilities.

(4)

The liabilities listed as of March 31, 2015 and December 31, 2014 above represent the contingent consideration for the Company’s acquisitions in 2011 for which the measurement periods for purchase price analyses for the acquisitions have concluded.

 

The Company did not have any transfers between Levels 1 and 2 of financial assets or liabilities that are fair valued on a recurring basis during the three months ended March 31, 2015 and 2014.

 

 

The following is a summary of changes in Level 3 liabilities measured at fair value on a recurring basis during the three months ended March 31, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

Contingent

 

 

Consideration

 

 

(in thousands)

Balance at December 31, 2014

 

$

24,814 

Fair value adjustments included in other income (expense), net

 

 

746 

Contingent consideration settled

 

 

 —

Balance at March 31, 2015

 

$

25,560 

 

12


 

Table of Contents

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingent

 

 

Consideration

 

 

(in thousands)

Balance at December 31, 2013

 

$

46,022 

Fair value adjustments included in other income (expense), net

 

 

3,404 

Contingent consideration settled

 

 

(1,031)

Balance at March 31, 2014

 

$

48,395 

 

 

The fair values of the contingent consideration were estimated using an income approach based on the cash flows that the acquired entity is expected to generate in the future. This approach requires management to project revenues, operating expenses, working capital investment, capital spending and cash flows for the reporting unit over a multi-year period, as well as determine the weighted-average cost of capital to be used as a discount rate (weighted-average cost of capital inputs have ranged from 14%-18%).

 

(6)     Goodwill and Intangible Assets

 

The Company tests goodwill and intangible assets with indefinite lives for impairment by applying a fair value test in the fourth quarter of each year and between annual tests if events occur or circumstances change that suggest a material adverse change to the most recently concluded valuation. The Company did not observe any changes in facts or circumstances during the three months ended March 31, 2015 that would indicate a material adverse change to the fourth quarter 2014 concluded valuation.

 

The Company tests intangible assets with finite lives for impairment whenever events or circumstances indicate that the carrying value may not be recoverable. The Company did not observe any events or circumstances during the three months ended March 31, 2014 that would indicate that the carrying value of its intangible assets may not be recoverable.

 

The following table presents the carrying amount of goodwill allocated to the Company’s reporting units as of March 31, 2015:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

Civil

 

Building

 

Contractors

 

Total

 

 

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Goodwill Balance

 

$

492,074 

 

$

424,724 

 

$

156,193 

 

$

1,072,991 

Accumulated Impairment

 

 

(76,716)

 

 

(411,269)

 

 

 —

 

 

(487,985)

Balance at December 31, 2014

 

$

415,358 

 

$

13,455 

 

$

156,193 

 

$

585,006 

Current activity

 

 

 —

 

 

 —

 

 

 —

 

 

Balance at March 31, 2015

 

$

415,358 

 

$

13,455 

 

$

156,193 

 

$

585,006 

 

 

 

Intangible assets consist of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

March 31, 2015

 

Weighted

 

 

 

 

 

 

 

 

Accumulated

 

 

 

 

Average

 

 

 

 

 

Accumulated

 

Impairment

 

Carrying

 

Amortization

 

 

Cost

 

Amortization

 

Charge

 

Value

 

Period

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Trade names (non-amortizable)

 

$

117,600 

 

$

 —

 

$

(67,190)

 

$

50,410 

 

Indefinite

Trade names (amortizable)

 

 

74,350 

 

 

(9,451)

 

 

(23,232)

 

 

41,667 

 

20 years

Contractor license

 

 

6,000 

 

 

 —

 

 

(6,000)

 

 

 —

 

Indefinite

Customer relationships

 

 

39,800 

 

 

(15,921)

 

 

(16,645)

 

 

7,234 

 

11.4 years

Construction contract backlog

 

 

73,706 

 

 

(73,706)

 

 

 —

 

 

 —

 

3.6 years

Total

 

$

311,456 

 

$

(99,078)

 

$

(113,067)

 

$

99,311 

 

 

 

 

 

13


 

Table of Contents

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

December 31, 2014

 

Weighted

 

 

 

 

 

 

 

 

Accumulated

 

 

 

 

Average

 

 

 

 

 

Accumulated

 

Impairment

 

Carrying

 

Amortization

 

 

 

Cost

 

Amortization

 

Charge

 

Value

 

Period

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Trade names (non-amortizable)

 

$

117,600 

 

$

 —

 

$

(67,190)

 

$

50,410 

 

Indefinite

Trade names (amortizable)

 

 

74,350 

 

 

(8,829)

 

 

(23,232)

 

 

42,289 

 

20 years

Contractor license

 

 

6,000 

 

 

 —

 

 

(6,000)

 

 

 —

 

Indefinite

Customer relationships

 

 

39,800 

 

 

(15,600)

 

 

(16,645)

 

 

7,555 

 

11.4 years

Construction contract backlog

 

 

73,706 

 

 

(73,706)

 

 

 —

 

 

 —

 

3.6 years

Total

 

$

311,456 

 

$

(98,135)

 

$

(113,067)

 

$

100,254 

 

 

 

 

Amortization expense for the three months ended March 31, 2015 totaled $0.9 million. As of March 31, 2015, amortization expense is estimated to be $2.8 million for the remainder of 2015, $3.5 million in 2016, $3.5 million in 2017, $3.5 million in 2018, $3.5 million in 2019 and $32.1 million thereafter.

 

(7) Contingencies and Commitments

 

The Company and certain of its subsidiaries are involved in litigation and are contingently liable for commitments and performance guarantees arising in the ordinary course of business. The Company and certain of its clients have made claims arising from the performance under their contracts. The Company recognizes certain significant claims for recovery of incurred cost when it is probable that the claim will result in additional contract revenue and when the amount of the claim can be reliably estimated. These assessments require judgments concerning matters such as litigation developments and outcomes, the anticipated outcome of negotiations, the number of future claims and the cost of both pending and future claims. In addition, because most contingencies are resolved over long periods of time, liabilities may change in the future due to various factors.

 

Several matters are in the litigation and dispute resolution process. The following discussion provides a background and current status of these matters.

 

Tutor-Saliba-Perini Joint Venture vs. Los Angeles MTA Matter

 

During 1995 Tutor-Saliba-Perini (“Joint Venture”) filed a complaint in the Superior Court of the State of California for the County of Los Angeles against the Los Angeles County Metropolitan Transportation Authority (“LAMTA”), seeking to recover costs for extra work required by LAMTA in connection with the construction of certain tunnel and station projects, all of which were completed by 1996. In 1999, LAMTA countered with civil claims under the California False Claims Act against the Joint Venture, Tutor-Saliba and the Company jointly and severally (together, “TSP”), and obtained a judgment that was reversed on appeal and remanded for retrial before a different judge.

 

Between 2005 and 2010, the court granted certain Joint Venture motions and LAMTA capitulated on others, which reduced the number of false claims LAMTA may seek and limited LAMTA’s claims for damages and penalties. In September 2010, LAMTA dismissed its remaining claims and agreed to pay the entire amount of the Joint Venture’s remaining claims plus interest. In the remanded proceedings, the Court subsequently entered judgment in favor of TSP and against LAMTA in the amount of $3.0 million after deducting $0.5 million, representing the tunnel handrail verdict plus accrued interest against TSP. The parties filed post-trial motions for costs and fees. The Court ruled that TSP’s sureties could recover costs, LAMTA could recover costs for the tunnel handrail trial, and no party could recover attorneys’ fees. TSP appealed the false claims jury verdict on the tunnel handrail claim and other issues, including the denial of TSP’s and its sureties’ request for attorneys’ fees. LAMTA subsequently filed its cross-appeal. In June 2014, the Court of Appeal issued its decision reversing judgment on the People’s Unfair Competition claim and reversing the denial of TSP’s Sureties’ request for attorney’s fees and affirming the remainder of the judgment. In January 2015, payment was made by LAMTA in the amount of $3.8 million in settlement of all outstanding issues except for the attorney’s fees for TSP’s Sureties.

 

Subsequent to the Court of Appeal’s June 2014 decision, LAMTA filed a request for hearing before the California Supreme Court, challenging the Court of Appeal’s decision that TSP’s Sureties are entitled to attorney’s fees. In September 2014, the Supreme Court denied the MTA’s petition for Review. In September 2014, the Court of Appeal remitted the case back to the trial court to make further rulings consistent with the decision of the Court of Appeal. In November 2014, the court set the hearing on the motion for TSP’s Surety’s attorney’s fees for March 2015, the date of which was subsequently re-set for May 1, 2015.

 

The Company does not expect this matter to have any material effect on its consolidated financial statements.

 

14


 

Table of Contents

 

Long Island Expressway/Cross Island Parkway Matter

 

The Company reconstructed the Long Island Expressway/Cross Island Parkway Interchange project for the New York State Department of Transportation (the “NYSDOT”). The $130 million project was substantially completed in January 2004 and was accepted by the NYSDOT as finally complete in February 2006. The Company incurred significant added costs in completing its work and suffered extended schedule costs due to numerous design errors, undisclosed utility conflicts, lack of coordination with local agencies and other interferences for which the Company believes that the NYSDOT is responsible.

 

In March 2011, the Company filed its claim and complaint with the New York State Court of Claims and served to the New York State Attorney General’s Office, seeking damages in the amount of $53.8 million. In May 2011, the NYSDOT filed a motion to dismiss the Company’s claim on the grounds that the Company had not provided required documentation for project closeout and filing of a claim. In September 2011, the Company reached agreement on final payment with the Comptroller’s Office on behalf of the NYSDOT which resulted in an amount of $0.5 million payable to the Company and formally closed out the project, which allowed the Company’s claim to be re-filed. The Company re-filed its claim in the amount of $53.8 million with the NYSDOT in February 2012 and with the Court of Claims in March 2012. In May 2012, the NYSDOT served its answer and counterclaims in the amount of $151 million alleging fraud in the inducement and punitive damages related to disadvantaged business enterprise (“DBE”) requirements for the project. The Court subsequently ruled that NYSDOT’s counterclaims may only be asserted as a defense and offset to the Company’s claims and not as affirmative claims. The Company does not expect the counterclaim to have any material effect on its consolidated financial statements.

 

In November 2014, the Appellate Division First Department affirmed the dismissal of the City’s affirmative defenses and counterclaims based on DBE fraud. Discovery is ongoing.

 

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Fontainebleau Matter

 

Desert Mechanical Inc. (“DMI”) and Fisk Electric Company (“Fisk”), wholly owned subsidiaries of the Company, were subcontractors on the Fontainebleau Project in Las Vegas (“Fontainebleau”), a hotel/casino complex with approximately 3,800 rooms. In June 2009, Fontainebleau filed for bankruptcy protection, under Chapter 11 of the U.S. Bankruptcy Code, in the Southern District of Florida. Fontainebleau is headquartered in Miami, Florida.

 

DMI and Fisk filed liens in Nevada for approximately $44 million, representing unreimbursed costs to date and lost profits, including anticipated profits. Other unaffiliated subcontractors have also filed liens. In June 2009, DMI filed suit against Turnberry West Construction, Inc. (“Turnberry”), the general contractor, in the 8th Judicial District Court, Clark County, Nevada, and in May 2010, the court entered an order in favor of DMI for approximately $45 million.

 

In January 2010, the Bankruptcy Court approved the sale of the property to Icahn Nevada Gaming Acquisition, LLC, and this transaction closed in February 2010. As a result of a July 2010 ruling relating to certain priming liens, there was approximately $125 million set aside from this sale, which is available for distribution to satisfy the creditor claims based on seniority. At that time, the total estimated sustainable lien amount was approximately $350 million. The project lender filed suit against the mechanic’s lien claimants, including DMI and Fisk, alleging that certain mechanic’s liens are invalid and that all mechanic’s liens are subordinate to the lender’s claims against the property. The Nevada Supreme Court ruled in October 2012 in an advisory opinion at the request of the Bankruptcy Court that lien priorities would be determined in favor of the mechanic lien holders under Nevada law.

 

In October 2013, a settlement was reached by and among the Statutory Lienholders and the other interested parties. The agreed upon settlement has not had an impact on the Company’s recorded accounting position as of the period ended March 31, 2015. The execution of that settlement agreement continues under the supervision of a mediator appointed by the Bankruptcy Court. Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Honeywell Street/Queens Boulevard Bridges Matter

 

In 1999, the Company was awarded a contract for reconstruction of the Honeywell Street/Queens Boulevard Bridges project for the City of New York (the “City”). In June 2003, after substantial completion of the project, the Company initiated an action to recover $8.8 million in claims against the City on behalf of itself and its subcontractors. In March 2010, the City filed counterclaims for $74.6 million and other relief, alleging fraud in connection with the DBE requirements for the project. In May 2010, the Company served the City with its response to the City’s counterclaims and affirmative defenses. In August 2013, the Court granted TPC’s motion to dismiss the City’s affirmative defenses and counterclaims relating to fraud. In September 2013, the City filed a Notice of Appeal to

15


 

Table of Contents

 

the Court’s decision; said appeal was dismissed by the Appellate Court in November 2014.  In February 2015, the Court set a due date of July 2015 for the Note of Issue to be filed, at which point it is expected case will be scheduled for trial.

 

The Company does not expect this matter to have any material effect on its consolidated financial statements.

 

Westgate Planet Hollywood Matter

 

Tutor-Saliba Corporation (“TSC”), a wholly owned subsidiary of the Company, contracted to construct a time share development project in Las Vegas which was substantially completed in December 2009. The Company’s claims against the owner, Westgate Planet Hollywood Las Vegas, LLC (“WPH”), relate to unresolved owner change orders and other claims. The Company filed a lien on the project in the amount of $23.2 million, and filed its complaint with the District Court, Clark County, Nevada. Several subcontractors have also recorded liens, some of which have been released by bonds and some of which have been released as a result of subsequent payment. WPH has posted a mechanic’s lien release bond for $22.3 million.

 

WPH filed a cross-complaint alleging non-conforming and defective work for approximately $51 million, primarily related to alleged defects, misallocated costs, and liquidated damages. WPH revised the amount of their counterclaims to approximately $45 million.

 

Following multiple post-trial motions, final judgment was entered in this matter on March 20, 2014. TSC was awarded total judgment in the amount of $19.7 million on its breach of contract claim, which includes an award of interest up through the date of judgment, plus attorney’s fees and costs. WPH has paid $0.6 million of that judgment. WPH was awarded total judgment in the amount of $3.1 million on its construction defect claims, which includes interest up through the date of judgment. The awards are not offsetting. WPH and its Sureties have filed a notice of appeal. TSC has filed a notice of appeal on the defect award. In July 2014, the Court ordered WPH to post an additional supersedeas bond on appeal, in the amount of $1.7 million, in addition to the lien release bond of $22.3 million, which increases the security up to $24.0 million. Oral argument on the appeals is anticipated to be scheduled for early 2016.

 

The Company does not expect this matter to have any material effect on its consolidated financial statements. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

Brightwater Matter

 

In 2006, the Department of Natural Resources and Parks Wastewater Treatment Division of King County (“King County”), as Owner, and Vinci Construction Grands Projects/Parsons RCI/Frontier-Kemper, Joint Venture (“VPFK”), as Contractor, entered into a contract to construct the Brightwater Conveyance System and tunnel sections in Washington State. Frontier-Kemper, a wholly owned subsidiary of the Company, is a 20% minority partner in the joint venture.

 

In April 2010, King County filed a lawsuit alleging damages in the amount of $74 million, plus costs, for VPFK’s failure to complete specified components of the project in the King County Superior Court, State of Washington. Shortly thereafter, VPFK filed a counterclaim in the amount of approximately $75 million, seeking reimbursement for additional costs incurred as a result of differing site conditions, King County’s defective specifications, for damages sustained on VPFK’s tunnel boring machines (“TBM”), and increased costs as a result of hyperbaric interventions. VPFK’s claims related to differing site conditions, defective design specifications, and damages to the TBM were presented to a Dispute Resolution Board (“DRB”). King County amended the amount sought in its lawsuit to approximately $132 million. In August 2011, the DRB generally found that King County was liable to VPFK for VPFK’s claims for encountering differing site conditions, including damages to the TBM, but not on VPFK’s alternative theory of defective specifications. From June through August 2012, each party filed several motions for summary judgment on certain claims and requests in preparation for trial, which were heard and ruled upon by the Court. The Court granted and denied various requests of each party related to evidence and damages.

 

In December 2012, a jury verdict was received in favor of King County in the amount of $155.8 million and a verdict in favor of VPFK in the amount of $26.3 million. In late April 2013, the Court ruled on post-trial motions and ordered VPFK’s sureties to pay King County’s attorneys’ fees and costs in the amount of $14.7 million. All other motions were denied. On May 7, 2013, VPFK paid the full verdict amount and the associated fees, thus terminating any interest on the judgment. VPFK’s notice of appeal was filed on May 31, 2013. King County has appealed approximately $17.0 million of the verdict award in VPFK’s favor and VPFK’s sureties have appealed the Court’s order granting King County’s request for legal fees and costs. Oral argument was held on March 9, 2015 and a decision is expected within three to six months.

 

The ultimate financial impact of King County’s lawsuit is not yet specifically determinable. In the fourth quarter of 2012, management developed a range of possible outcomes and has recorded a charge to income and a contingent liability of $5.0 million in accrued expenses. In developing a range of possible outcomes, management considered the jury verdict, continued litigation and potential settlement strategies. Management determined that there was no estimate within the range of possible outcomes that was more probable than the other and recorded a liability at the low end of the range. As of March 31, 2015, there were no changes in facts or

16


 

Table of Contents

 

circumstances that led management to believe that there were any changes to the probability of outcomes. The amount of payments in excess of the established contingent liability is recorded in Accounts Receivable on the Company’s Consolidated Condensed Balance Sheet as of March 31, 2015. Estimating and recording future outcomes of litigation proceedings require significant judgment and assumptions about the future, which are inherently subject to risks and uncertainties. If a final recovery turns out to be materially less favorable than our estimates, this may have a significant impact on the Company’s financial results. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

156 Stations Matter

 

In December 2003, Five Star Electric Corporation (“FSE”), a wholly owned subsidiary of the Company, entered into an agreement with the Prime Contractor Transit Technologies, L.L.C (“Transit”), a Consortium member of Siemens Transportation Transit Technologies, L.L.C (“Siemens”), to assist in the installation of new public address and customer information screens system for each of the 156 stations for the New York City Transit Authority (“NYCTA”) as the owner.

 

In June 2012, an arbitration panel awarded FSE a total of approximately $11.9 million. Subsequently, the Court affirmed FSE’s position, however, decided that only $8.5 million of the total arbitration award of $11.9 million can be recovered against the payment bond. In December 2014, FSE filed its reply for the motion for re-argument with regard to the reduction in recoverable costs against the payment bond.

 

This matter was fully settled in April 2015 and payment was received. The settlement amount was consistent with the Company’s recorded position and, accordingly, the settlement did not have a material impact on the Company’s consolidated financial statements.

 

U.S. Department of Commerce, National Oceanic and Atmospheric Administration Matter

Rudolph and Sletten, Inc. (“R&S”), a wholly owned subsidiary of the Company, entered into a contract with the United States Department of Commerce, National Oceanic and Atmospheric Administration (“NOAA” or “Owner”) for the construction of a 287,000 square-foot facility for NOAA’s Southwest Fisheries Science Center Replacement Headquarters and Laboratory in La Jolla, California. The contract work began on May 24, 2010, and was substantially completed in September 2012. R&S incurred significant additional costs as a result of a design that contained errors and omissions, NOAA’s unwillingness to correct design flaws in a timely fashion and a refusal to negotiate the time and pricing associated with change order work.

 

R&S has filed three certified claims against NOAA for contract adjustments related to the unresolved Owner change orders, delays, design deficiencies and other claims. The First Certified Claim was submitted on August 20, 2013, in the amount of $26.8 million ("First Certified Claim") and the second certified claim was submitted on October 30, 2013, in the amount of $2.6 million ("Second Certified Claim") and the Third Certified Claim was submitted on October 1, 2014 in the amount of $0.7 million.

 

NOAA requested an extension of nine months to issue a decision on the First Certified Claim, but did not request an extension of time related to review of the Second Certified Claim. On January 6, 2014, R&S filed suit in the United States Federal Court of Claims on the Second Certified Claim plus interest and attorney's fees and costs. This was followed by submission of a law suit on the First Certified Claim on July 31, 2014. In October 2014, the court ordered that the two lawsuits be consolidated for purposes of oral argument on the respective Motions to Dismiss. In February 2015 the Court denied NOAA’s motion to dismiss the Second Certified Claim. In March 2014 the Contracting Officer issued decisions on all Claims accepting a total of approximately $1.0 million of the Claims. The Court has ordered both parties to submit a joint status summary setting forth whether the case should now be consolidated and a schedule for discovery should be set.

 

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

 

(8)     Income Taxes

 

The Company’s income tax provision was  $3.1 million for the three months ended March 31, 2015, compared to the income tax provision of  $11.4 million for the three months ended March 31, 2014. The effective income tax rate was 37.5% as compared to 41.6% for the same period in 2014.

 

As of March 31, 2015, the total amount of unrecognized tax benefits, including related interest and penalties was $7.8 million. If the total amount of unrecognized tax benefits was recognized, $6.9 million of unrecognized tax benefits and $0.9 million of interest would decrease the effective tax rate.

 

(9)     Stock-Based Compensation

 

17


 

Table of Contents

 

The Company is authorized to grant up to 8,500,000 stock-based compensation awards to key executives, employees and directors of the Company under the Amended and Restated Tutor Perini Corporation Long-Term Incentive Plan (the “Plan”). The Plan allows stock-based compensation awards to be granted in a variety of forms, including stock options, stock appreciation rights, restricted stock unit awards, unrestricted stock awards, deferred stock awards and dividend equivalent rights. The terms and conditions of the awards granted are established by the Compensation Committee of the Company’s Board of Directors who also administers the Plan.

 

The Company intends to settle stock awards in shares upon vesting to the extent that the Company has shares available under the Plan. A total of 114,928 shares of common stock remain available for future grant under the Plan at March 31, 2015.

 

Restricted Stock Unit Awards

 

Restricted stock unit awards generally vest subject to the satisfaction of service requirements or the satisfaction of both service requirements and achievement of certain performance targets. Upon vesting, each restricted stock unit award is exchanged for one share of the Company’s common stock. The grant date fair values of these awards are determined based on the closing price of the Company’s stock on either the award date (if subject only to service conditions), or the date that the Compensation Committee establishes the applicable performance target (if subject to performance conditions). The related compensation expense is amortized over the applicable requisite service period. As of March 31, 2015, the Compensation Committee has approved the grant of an aggregate of 6,228,430 restricted stock unit awards under the 2004 Stock Option and Incentive Plan (and amendments) to eligible participants.

 

During March of 2015, the Compensation Committee established the 2015 performance targets for 291,500 restricted stock units awarded in 2015, 2013, and 2012. The restricted stock unit awards granted during the first quarter of 2015 had a weighted average grant date fair value of $23.35. The grant date fair value is determined based on the closing price of the Company’s common stock on the date of the grant.

 

During March of 2014, the Compensation Committee established the 2014 performance targets for 866,500 restricted stock units awarded in 2014, 2013, and 2012. The restricted stock unit awards granted during the first quarter of 2014 had a weighted average grant date fair value of $27.33. The grant date fair value is determined based on the closing price of the Company’s common stock on the date of the grant.

 

1,560 restricted stock unit awards were forfeited during the three months ended March 31, 2015.

 

During the three months ended March 31, 2015 and 2014, the Company recognized $5.6 million and $3.9 million, respectively, of compensation expense related to restricted stock unit awards, and such expense is included in general and administrative expenses in the Consolidated Statements of Operations. As of March 31, 2015,  there was $19.9 million of unrecognized compensation cost related to the unvested awards which, absent significant forfeitures in the future, is expected to be recognized over a weighted average period of approximately 2.5 years.

 

A summary of restricted stock unit awards activity for the three months ended March 31, 2015 is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Aggregate

 

 

 

 

 

Weighted Average

 

Intrinsic

 

 

 

Number

 

Grant Date

 

Value

 

 

 

of Shares

 

Fair Value

 

(in thousands)

Granted and Unvested - January 1, 2015

 

 

1,056,597 

 

$

26.54 

 

$

25,432 

Activity during the three months ended March 31, 2015:

 

 

 

 

 

 

 

 

 

Vested

 

 

(335,940)

 

$

27.64 

 

$

7,323 

Granted

 

 

291,500 

 

$

23.35 

 

$

6,807 

Forfeited

 

 

(1,560)

 

$

28.59 

 

$

 —

          Total Granted and Unvested - March 31, 2015

 

 

1,010,597 

 

$

27.78 

 

$

23,597 

Approved for grant

 

 

709,500 

 

 

(a)

 

$

16,567 

Total Awarded and Unvested - March 31, 2015

 

 

1,720,097 

 

 

n.a.

 

$

40,164 

 

 


(a)

Grant date fair value cannot be determined currently because the related performance targets for future years have not yet been established by the Compensation Committee.

 

18


 

Table of Contents

 

The outstanding unvested awards at March 31, 2015 are scheduled to vest as follows, subject where applicable to the achievement of performance targets. As described above, certain performance targets are not yet established.

 

 

 

 

 

 

 

 

 

Number

Vesting Date

 

of Awards

2015

 

5,000 

2016

 

302,500 

2017

 

957,597 

2018

 

296,000 

2019

 

159,000 

 

 

1,720,097 

 

35,000 of the unvested restricted stock unit awards will vest based on the satisfaction of service requirements and 1,685,097 of the unvested restricted stock unit awards will vest based on the satisfaction of both service requirements and the achievement of performance targets.

 

Stock Options

 

Stock option awards generally vest subject to the satisfaction of service requirements or the satisfaction of both service requirements and achievement of certain performance targets. The grant date fair values of these awards are determined based on the Black-Scholes option price model on either the award date (if subject only to service conditions) or the date that the Compensation Committee establishes the applicable performance target (if subject to performance conditions). The related compensation expense is amortized over the applicable requisite service period. The exercise price of the options is equal to the closing price of the Company’s common stock on the date the awards were approved by the Compensation Committee, and the awards expire ten years from the award date. As of March 31, 2015, the Compensation Committee has approved the award of an aggregate of 3,385,465 stock options to eligible participants.

 

In March 2015, the Compensation Committee established certain performance targets for 259,000 stock options awarded in 2015, 2014, 2013, and 2012. The stock option awards granted during the first quarter of 2015 had a weighted average grant date fair value of $12.64.

 

In March 2014, the Compensation Committee established certain performance targets for 714,000 stock options awarded in 2014, 2013 and 2012. The stock option awards granted during the first quarter of 2014 had a weighted average grant date fair value of $17.69. 

 

For the three months ended March 31, 2015 and 2014, the Company recognized compensation expense of $3.6 million and $1.5 million, respectively, related to stock option awards, and such expenses are included in general and administrative expenses in the Consolidated Statements of Operations. As of March 31, 2015, there was $7.5 million of unrecognized compensation expense related to the outstanding options, which, absent significant forfeitures in the future, is expected to be recognized over a weighted average period of approximately 2.4 years.

 

A summary of stock option activity for the three months ended March 31, 2015 is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted Average

 

 

 

Number

 

Grant Date

 

Exercise

 

 

 

of Shares

 

Fair Value

 

Price

Total Granted and Outstanding - January 1, 2015

 

 

1,989,000 

 

$

12.75 

 

$

19.63 

Activity during the three months ended March 31, 2015:

 

 

 

 

 

 

 

 

 

Granted

 

 

259,000 

 

$

12.64 

 

$

16.07 

Exercised

 

 

 —

 

$

 —

 

$

 —

Forfeited

 

 

 —

 

$

 —

 

$

 —

        Total Granted and Outstanding - March 31, 2015

 

 

2,248,000 

 

$

12.50 

 

$

19.22 

Approved for grant

 

 

677,000 

 

 

(a)

 

 

20.75 

Total Awarded and Outstanding - March 31 2015

 

 

2,925,000 

 

 

n.a.

 

 

19.57 

 

 

 


(a)

Grant date fair value cannot be determined currently because the related performance targets for future years have not yet been established by the Compensation Committee.

 

19


 

Table of Contents

 

There were 1,485,000 stock options that have vested and were exercisable at March 31, 2015 at a weighted average exercise price of $19.57 per share.

 

Of the remaining stock options outstanding, approximately 475,000 stock options will vest based on the satisfaction of service requirements and 2,450,000 stock options will vest based on the satisfaction of both service requirements and the achievement of performance targets.

 

At March 31, 2015, the outstanding stock options of 2,248,000 had an intrinsic value of $11.2 million and a weighted average remaining contractual life of 5.9 years.

 

The following table details the key assumptions used in estimating the grant date fair values of stock option awards granted during the first quarter of 2015 based on the Black Scholes option pricing model using the following key assumptions:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Awarded during

 

 

2015

 

 

 

2013

 

 

 

2013

 

 

 

2012

 

 

 

 

 

Number of options

 

 

100,000 

 

 

 

5,000 

 

 

 

4,000 

 

 

 

150,000 

 

 

 

 

 

Risk-free interest rate

 

 

1.46 

%

 

 

1.67 

%

 

 

1.67 

%

 

 

1.15 

%

 

 

 

 

Expected life of options (years)

 

 

5.50 

 

 

 

6.76 

 

 

 

6.75 

 

 

 

4.06 

 

 

 

 

 

Expected volatility of underlying stock

 

 

45.11 

%

 

 

49.29 

%

 

 

49.29 

%

 

 

45.92 

%

 

 

 

 

Expected quarterly dividends (per share)

 

$

0.00 

 

 

$

0.00 

 

 

$

0.00 

 

 

$

0.00 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(10)     Financial Commitments

 

Amended Credit Agreement

 

On June 5, 2014, the Company entered into a Sixth Amended and Restated Credit Agreement, (the “Credit Facility”) restructuring its former $300 million revolving credit facility and $200 million Term Loan. All outstanding amounts under the Fifth Amended and Restated Credit Agreement were repaid in full using proceeds of the Credit Facility. The new agreement provides for a $300 million revolving credit facility (the “Revolving Credit Facility") and a $250 million term loan (the “Term Loan”) with Bank of America, N.A. as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The Term Loan principal is to be repaid on a quarterly basis, with 6.0% of the original total outstanding principal repaid in year 1, 9.0% in year 2, 12.0% in year 3, 15.0% in year 4 and 13.5% in year 5 along with a balloon payment of the remaining 44.5% due at maturity. Borrowings under the Revolving Credit Facility bear interest based either on Bank of America’s prime lending rate or the London Interbank Offered Rate (“LIBOR”) plus an applicable margin. Borrowings under the Term Loan bear interest based on LIBOR plus an applicable margin. Included in the Credit Facility is a special provision allowing an additional accordion provision, which the Company may opt to utilize at a future date to increase either the Revolving Credit Facility or establish one or more new term loan commitments, up to an aggregate amount not to exceed $300 million. The Credit Facility provides a sublimit for the issuance of letters of credit up to the aggregate amount of $150 million. Both the Revolving Credit Facility and the Term Loan mature on June 5, 2019.

 

The Revolving Credit Facility and Term Loan include usual and customary covenants for credit facilities of this type, including covenants providing maximum allowable ranges of consolidated leverage ratios from 3.75:1.00 to 2.75:1.00 over a range of five years and maintaining a minimum consolidated fixed charge coverage ratio of 1.25:1.00. The Credit Facility eliminated the other covenant requirements that were formerly held under the Fifth Amended and Restated Credit Agreement.

 

Substantially all of the Company’s subsidiaries unconditionally guarantee the obligations of the Company under the Credit Facility. The obligations under the Credit Facility are secured by a lien on all personal property of the Company and its subsidiaries party thereto. Any outstanding loans under the Revolving Facility and the Term Loan mature on June 5, 2019. The Term Loan balance was $238.8 million at March 31, 2015. The Company was in compliance with the financial covenants under the Credit Facility for the period ended March 31, 2015.

 

The Company had $185.0 million of outstanding borrowings under its Revolving Facility as of March 31, 2015 and $130.0 million as of December 31, 2014. The net change in borrowings under the Revolving Facility comprises all “Proceeds from debt” and a significant portion of all “Repayment of debt” as presented in the Consolidated Condensed Statements of Cash Flows. The Company utilized the Revolving Facility for letters of credit in the amount of $0.2 million as of March 31, 2015 and $1.0 million as of December 31, 2014. Accordingly, at March 31, 2015, the Company had $114.8 million available to borrow under the Revolving Facility.

 

20


 

Table of Contents

 

(11)     Earnings per Common Share

 

Basic earnings per common share were computed by dividing net income by the weighted average number of common shares outstanding. Diluted earnings per common share were similarly computed after giving consideration to the dilutive effect of stock options and restricted stock unit awards outstanding on the weighted average number of common shares outstanding. The computation of diluted earnings per common share for the three months ended March 31, 2015 excluded the antidilutive effect of 10,000 antidilutive restricted stock awards. The computation of diluted earnings per common share for the three months ended March 31, 2015 excluded the antidilutive effect of 519,000 stock options. The computation of diluted earnings per common share excluded 260,000 stock option shares during the three months ended March 31, 2014 because these shares would have an antidilutive effect.

  

(12)     Business Segments

 

The Company’s chief operating decision maker is the Chairman and Chief Executive Officer, who decides how to allocate resources and assess performance of the business segments. Generally, the Company evaluates performance of its operating segments on the basis of income from construction operations and cash flow.

 

The following table sets forth certain reportable segment information relating to the Company’s operation for the three months ended March 31, 2015 and 2014 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Specialty

 

 

 

 

 

 

 

 

Consolidated

(in thousands)

 

Civil

 

 

Building

 

Contractors

 

Totals

 

Corporate

 

 

Total

Three Months Ended March 31, 2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

 

$

392,876 

 

$

416,063 

 

$

293,017 

 

$

1,101,956 

 

$

 —

 

 

$

1,101,956 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Elimination of intersegment revenues

 

 

(18,202)

 

 

(17,233)

 

 

(56)

 

 

(35,491)

 

 

 —

 

 

 

(35,491)

Revenues from external customers

 

$

374,674 

 

$

398,830 

 

$

292,961 

 

$

1,066,465 

 

$

 —

 

 

$

1,066,465 

Income from construction operations

 

$

30,593 

 

$

(2,279)

 

$

10,524 

 

$

38,838 

 

$

(18,754)

*

 

$

20,084 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended March 31, 2014

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenues

 

$

376,392 

 

$

311,315 

 

$

292,145 

 

$

979,852 

 

$

 —

 

 

$

979,852 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Elimination of intersegment revenues

 

 

(11,236)

 

 

(13,383)

 

 

 —

 

 

(24,619)

 

 

 —

 

 

 

(24,619)

Revenues from external customers

 

$

365,156 

 

$

297,932 

 

$

292,145 

 

$

955,233 

 

$

 —

 

 

$

955,233 

Income from construction operations

 

$

44,345 

 

$

1,823 

 

$

7,817 

 

$

53,985 

 

$

(12,488)

*

 

$

41,497 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 


* Consists primarily of corporate general and administrative expenses.

 

The following table sets forth certain reportable segment information relating to the Company’s total assets as of March 31, 2015 and December 31, 2014 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

March 31, 2015

 

December 31, 2014

 

 

 

 

 

 

 

Building

 

$

684,116 

 

$

680,933 

Civil

 

 

1,722,877 

 

 

1,814,170 

Specialty Contractors

 

 

801,699 

 

 

775,162 

  Totals

 

$

3,208,692 

 

$

3,270,265 

Corporate *

 

 

557,788 

 

 

503,050 

Consolidated Total

 

$

3,766,480 

 

$

3,773,315 

 


* Consists principally of Cash and Cash Equivalents and corporate transportation equipment.

 

21


 

Table of Contents

 

(13)     Employee Pension Plans

 

The Company has a defined benefit pension plan and an unfunded supplemental retirement plan. Effective September 1, 2004, all benefit accruals under the Company’s pension plan were frozen; however, the current vested benefit was preserved. The pension disclosure presented below includes aggregated amounts for both of the Company’s plans.

 

The following table sets forth the net periodic benefit cost by component for March 31, 2015 and 2014:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended March 31,

 

 

 

 

2015

 

 

2014

 

 

 

(in thousands)

 

Interest cost

 

$

1,011 

 

$

1,030 

 

Expected return on plan assets

 

 

(1,256)

 

 

(1,192)

 

Amortization of net loss

 

 

1,460 

 

 

1,077 

 

Net periodic benefit cost

 

$

1,215 

 

$

915 

 

 

The Company contributed $0.9 million and $0.6 million to its defined benefit pension plan during the three months ended 2015 and 2014, respectively. The Company expects to contribute an additional $1.8 million to its defined benefit pension plan during the remainder of fiscal year 2015.

 

 

(14)     Related Party Transactions

 

The Company leases certain facilities from Ronald N. Tutor, the Company’s Chairman and Chief Executive Officer, and an affiliate owned by Mr. Tutor under non-cancelable operating lease agreements. On April 18, 2014, the Company and Ronald N. Tutor entered into two separate lease agreements, replacing the former leases which terminated on May 31, 2014. Each of the new leases is effective June 1, 2014 with new monthly payments of an aggregate of $0.2 million, and an increase at the rate of the greater of 3% per annum or the Consumer Price Index (“CPI”) for the Los Angeles metropolitan area beginning on June 1, 2015. Both new leases provide for purchase/sell options of the facilities at fair market value beginning on June 1, 2021 and June 1, 2025. Also under both leases, the fair market value is to be agreed upon by both parties, or determined by a consensus of independent qualified appraisers. Lease expense for these new leases and the former leases until date of termination, recorded on a straight-line basis, was $0.8 million and $0.6 million for the three months ended March 31, 2015 and 2014, respectively.

 

Raymond R. Oneglia, who is the Vice Chairman of O&G Industries, Inc. (“O&G”), is a director of the Company. Currently the Company has a 30% interest in a joint venture with O&G as the sponsor involving a highway construction project for the State of Connecticut, with an estimated total contract value of approximately $362 million, scheduled for completion in 2016. Under this arrangement, O&G provides project-related equipment and services directly to the customer (on customary trade terms). In accordance with the joint venture agreement, payments to O&G for equipment and services for March 31, 2015 and March 31, 2014 were $2.0 million and $1.5 million, respectively. O&G’s cumulative holdings of the Company’s stock were 500,000 shares at both March 31, 2015 and March 31, 2014, or 1.02% and 1.03%, respectively, of total common shares outstanding.

 

(15)     Separate Financial Information of Subsidiary Guarantors of Indebtedness

 

The Company’s obligation to pay principal and interest on its 7.625% senior unsecured notes due November 1, 2018, is guaranteed on a joint and several basis by substantially all of the Company’s existing and future subsidiaries that guarantee obligations under the Company’s Sixth Amended Credit Agreement (the “Guarantors”). The guarantees are full and unconditional and the Guarantors are 100%-owned by the Company.

 

The following supplemental condensed consolidating financial information reflects the summarized financial information of the Company as the issuer of the senior unsecured notes, the Guarantors and the Company’s non-guarantor subsidiaries on a combined basis.

 

22


 

Table of Contents

 

CONDENSED CONSOLIDATING BALANCE SHEET - MARCH 31, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

 

ASSETS

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and Cash Equivalents

 

$

71,938 

 

$

49,241 

 

$

24,779 

 

$

 —

 

$

145,958 

 

Restricted Cash

 

 

3,369 

 

 

4,991 

 

 

35,733 

 

 

 —

 

 

44,093 

 

Accounts Receivable

 

 

363,404 

 

 

1,093,631 

 

 

36,982 

 

 

(99,897)

 

 

1,394,120 

 

Costs and Estimated Earnings in Excess of Billings

 

 

85,124 

 

 

771,851 

 

 

152 

 

 

(61,617)

 

 

795,510 

 

Deferred Income Taxes

 

 

 —

 

 

15,639 

 

 

 —

 

 

2,323 

 

 

17,962 

 

Other Current Assets

 

 

40,006 

 

 

43,169 

 

 

17,988 

 

 

(26,796)

 

 

74,367 

 

Total Current Assets

 

 

563,841 

 

 

1,978,522 

 

 

115,634 

 

 

(185,987)

 

 

2,472,010 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Investments

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Property and Equipment, net

 

 

89,708 

 

 

429,669 

 

 

4,245 

 

 

 —

 

 

523,622 

 

Intercompany Notes and Receivables

 

 

 —

 

 

176,388 

 

 

 —

 

 

(176,388)

 

 

 —

 

Other Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

   Goodwill

 

 

 —

 

 

585,006 

 

 

 —

 

 

 —

 

 

585,006 

 

   Intangible Assets, net

 

 

 —

 

 

99,311 

 

 

 —

 

 

 —

 

 

99,311 

 

   Investment in Subsidiaries

 

 

2,160,682 

 

 

19,516 

 

 

50 

 

 

(2,180,248)

 

 

 —

 

   Other

 

 

81,425 

 

 

10,625 

 

 

 —

 

 

(5,519)

 

 

86,531 

 

 

 

$

2,895,656 

 

$

3,299,037 

 

$

119,929 

 

$

(2,548,142)

 

$

3,766,480 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Current Maturities of Long-term Debt

 

$

34,733 

 

$

52,867 

 

 

 —

 

 

 —

 

$

87,600 

 

Accounts Payable

 

 

188,282 

 

 

730,611 

 

 

1,420 

 

 

(118,122)

 

 

802,191 

 

Billings in Excess of Costs and Estimated Earnings

 

 

129,662 

 

 

174,709 

 

 

34 

 

 

(18,363)

 

 

286,042 

 

Accrued Expenses and Other Current Liabilities

 

 

24,689 

 

 

85,045 

 

 

59,531 

 

 

(16,349)

 

 

152,916 

 

Total Current Liabilities

 

 

377,366 

 

 

1,043,232 

 

 

60,985 

 

 

(152,834)

 

 

1,328,749 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Debt, less current maturities

 

 

740,095 

 

 

96,166 

 

 

 —

 

 

(40,519)

 

 

795,742 

 

Deferred Income Taxes

 

 

142,104 

 

 

7,914 

 

 

 —

 

 

 —

 

 

150,018 

 

Other Long-term Liabilities

 

 

111,536 

 

 

1,971 

 

 

 —

 

 

 —

 

 

113,507 

 

Intercompany Notes and Advances Payable

 

 

145,689 

 

 

 —

 

 

28,619 

 

 

(174,308)

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingencies and Commitments

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Stockholders’ Equity

 

 

1,378,866 

 

 

2,149,754 

 

 

30,325 

 

 

(2,180,481)

 

 

1,378,464 

 

 

 

$

2,895,656 

 

$

3,299,037 

 

$

119,929 

 

$

(2,548,142)

 

$

3,766,480 

 

 

 

23


 

Table of Contents

 

CONDENSED CONSOLIDATING BALANCE SHEET - DECEMBER 31, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

 

ASSETS

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and Cash Equivalents

 

$

75,087 

 

$

36,764 

 

$

23,732 

 

$

 —

 

$

135,583 

 

Restricted Cash

 

 

3,369 

 

 

5,274 

 

 

35,727 

 

 

 —

 

 

44,370 

 

Accounts Receivable

 

 

299,427 

 

 

1,246,635 

 

 

37,064 

 

 

(103,622)

 

 

1,479,504 

 

Costs and Estimated Earnings in Excess of Billings

 

 

70,344 

 

 

700,362 

 

 

152 

 

 

(44,456)

 

 

726,402 

 

Deferred Income Taxes

 

 

 —

 

 

15,639 

 

 

 —

 

 

2,323 

 

 

17,962 

 

Other Current Assets

 

 

39,196 

 

 

42,750 

 

 

24,397 

 

 

(37,608)

 

 

68,735 

 

Total Current Assets

 

 

487,423 

 

 

2,047,424 

 

 

121,072 

 

 

(183,363)

 

 

2,472,556 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Investments

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

Property and Equipment, net

 

 

92,413 

 

 

430,876 

 

 

4,313 

 

 

 —

 

 

527,602 

 

Intercompany Notes and Receivables

 

 

 —

 

 

122,401 

 

 

 —

 

 

(122,401)

 

 

 —

 

Other Assets:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

   Goodwill

 

 

 —

 

 

585,006 

 

 

 —

 

 

 —

 

 

585,006 

 

   Intangible Assets, net

 

 

 —

 

 

100,254 

 

 

 —

 

 

 —

 

 

100,254 

 

   Investment in Subsidiaries

 

 

2,154,562 

 

 

19,519 

 

 

50 

 

 

(2,174,131)

 

 

 —

 

   Other

 

 

83,503 

 

 

9,847 

 

 

 —

 

 

(5,453)

 

 

87,897 

 

 

 

$

2,817,901 

 

$

3,315,327 

 

$

125,435 

 

$

(2,485,348)

 

$

3,773,315 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Current Maturities of Long-term Debt

 

$

34,776 

 

$

46,516 

 

$

 —

 

$

 —

 

$

81,292 

 

Accounts Payable

 

 

186,958 

 

 

716,851 

 

 

3,749 

 

 

(109,384)

 

 

798,174 

 

Billings in Excess of Costs and Estimated Earnings

 

 

139,020 

 

 

185,807 

 

 

2,672 

 

 

(8,203)

 

 

319,296 

 

Accrued Expenses and Other Current Liabilities

 

 

33,018 

 

 

95,177 

 

 

58,571 

 

 

(26,952)

 

 

159,814 

 

Total Current Liabilities

 

 

393,772 

 

 

1,044,351 

 

 

64,992 

 

 

(144,539)

 

 

1,358,576 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Long-term Debt, less current maturities

 

 

712,460 

 

 

112,060 

 

 

 —

 

 

(40,453)

 

 

784,067 

 

Deferred Income Taxes

 

 

142,457 

 

 

7,914 

 

 

 —

 

 

 —

 

 

150,371 

 

Other Long-term Liabilities

 

 

112,899 

 

 

1,897 

 

 

 —

 

 

 —

 

 

114,796 

 

Intercompany Notes and Advances Payable

 

 

90,373 

 

 

 —

 

 

35,619 

 

 

(125,992)

 

 

 —

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingencies and Commitments

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Stockholders’ Equity

 

 

1,365,939 

 

 

2,149,105 

 

 

24,824 

 

 

(2,174,363)

 

 

1,365,505 

 

 

 

$

2,817,900 

 

$

3,315,327 

 

$

125,435 

 

$

(2,485,347)

 

$

3,773,315 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

24


 

Table of Contents

 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED MARCH 31, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues

 

$

236,292 

 

$

885,103 

 

$

4,291 

 

$

(59,221)

 

$

1,066,465 

Cost of Operations

 

 

209,833 

 

 

825,094 

 

 

 —

 

 

(59,221)

 

 

975,706 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

 

26,459 

 

 

60,009 

 

 

4,291 

 

 

 —

 

 

90,759 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

25,035 

 

 

45,166 

 

 

474 

 

 

 —

 

 

70,675 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

INCOME FROM CONSTRUCTION OPERATIONS

 

 

1,424 

 

 

14,843 

 

 

3,817 

 

 

 —

 

 

20,084 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

11,940 

 

 

 —

 

 

 —

 

 

(11,940)

 

 

 —

Other (Expense) Income, net

 

 

(2,068)

 

 

1,196 

 

 

118 

 

 

 —

 

 

(754)

Interest Expense

 

 

(10,264)

 

 

(861)

 

 

 —

 

 

 —

 

 

(11,125)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (Loss) before Income Taxes

 

 

1,032 

 

 

15,178 

 

 

3,935 

 

 

(11,940)

 

 

8,205 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Benefit (Provision) for Income Taxes

 

 

4,094 

 

 

(5,696)

 

 

(1,477)

 

 

 —

 

 

(3,079)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME (LOSS)

 

$

5,126 

 

$

9,482 

 

$

2,458 

 

$

(11,940)

 

$

5,126 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 Other Comprehensive Income of Subsidiaries

 

 

(598)

 

 

 —

 

 

 —

 

 

598 

 

 

 —

 Foreign currency translation

 

 

 —

 

 

(588)

 

 

 —

 

 

 —

 

 

(588)

 Change in fair value of investments

 

 

 —

 

 

(10)

 

 

 —

 

 

 —

 

 

(10)

 Change in fair value of interest rate swap

 

 

45 

 

 

 —

 

 

 —

 

 

 —

 

 

45 

 Total Other Comprehensive (Loss) Income

 

 

(553)

 

 

(598)

 

 

 —

 

 

598 

 

 

(553)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

4,573 

 

$

8,884 

 

$

2,458 

 

$

(11,342)

 

$

4,573 

 

 

25


 

Table of Contents

 

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED MARCH 31, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

Revenues

 

$

226,847 

 

$

763,636 

 

 

 —

 

$

(35,250)

 

$

955,233 

Cost of Operations

 

 

193,814 

 

 

697,908 

 

 

(6,586)

 

 

(35,250)

 

 

849,886 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Gross Profit

 

 

33,033 

 

 

65,728 

 

 

6,586 

 

 

 —

 

 

105,347 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

General and Administrative Expenses

 

 

17,795 

 

 

45,620 

 

 

435 

 

 

 —

 

 

63,850 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(LOSS) INCOME FROM CONSTRUCTION OPERATIONS

 

 

15,238 

 

 

20,108 

 

 

6,151 

 

 

 —

 

 

41,497 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity in Earnings of Subsidiaries

 

 

15,281 

 

 

 —

 

 

 —

 

 

(15,281)

 

 

 —

Other (Expense) Income, net

 

 

(4,095)

 

 

602 

 

 

120 

 

 

 —

 

 

(3,373)

Interest Expense

 

 

(10,017)

 

 

(814)

 

 

 —

 

 

 —

 

 

(10,831)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (Loss) before Income Taxes

 

 

16,407 

 

 

19,896 

 

 

6,271 

 

 

(15,281)

 

 

27,293 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Provision for Income Taxes

 

 

(468)

 

 

(8,277)

 

 

(2,609)

 

 

 —

 

 

(11,354)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

NET INCOME (LOSS)

 

$

15,939 

 

$

11,619 

 

$

3,662 

 

$

(15,281)

 

$

15,939 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other Comprehensive Income of Subsidiaries

 

 

(105)

 

 

 —

 

 

 —

 

 

105 

 

 

 —

Tax adjustment on minimum pension liability

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

Foreign currency translation

 

 

 —

 

 

(286)

 

 

 —

 

 

 —

 

 

(286)

Change in fair value of investments

 

 

 —

 

 

181 

 

 

 —

 

 

 —

 

 

181 

Change in fair value of interest rate swap

 

 

81 

 

 

 —

 

 

 —

 

 

 —

 

 

81 

Total Other Comprehensive (Loss) Income

 

 

(24)

 

 

(105)

 

 

 —

 

 

105 

 

 

(24)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total Comprehensive Income (Loss)

 

$

15,915 

 

$

11,514 

 

$

3,662 

 

$

(15,176)

 

$

15,915 

 

 

 

 

 

 

26


 

Table of Contents

 

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

THREE MONTHS ENDED MARCH 31, 2015

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

 

Cash Flows from Operating Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income (loss)

 

$

5,126 

 

$

9,482 

 

$

2,458 

 

$

(11,940)

 

$

5,126 

 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Depreciation and amortization

 

 

5,223 

 

 

5,303 

 

 

68 

 

 

 —

 

 

10,594 

 

Equity in earnings of subsidiaries

 

 

(11,940)

 

 

 —

 

 

 —

 

 

11,940 

 

 

 —

 

Stock-based compensation expense

 

 

9,159 

 

 

 —

 

 

 —

 

 

 —

 

 

9,159 

 

Deferred income taxes

 

 

(24,392)

 

 

24,392 

 

 

 —

 

 

 —

 

 

 —

 

(Gain) loss on sale of investments

 

 

(17)

 

 

17 

 

 

 —

 

 

 —

 

 

 —

 

(Gain) loss on sale of property and equipment

 

 

17 

 

 

(293)

 

 

 —

 

 

 —

 

 

(276)

 

Other long-term liabilities

 

 

(1,288)

 

 

3,669 

 

 

 —

 

 

 —

 

 

2,381 

 

Other non-cash items

 

 

1,176 

 

 

(3,403)

 

 

 —

 

 

 —

 

 

(2,227)

 

Changes in other components of working capital 

 

 

(73,266)

 

 

43,701 

 

 

2,484 

 

 

 —

 

 

(27,081)

 

NET CASH (USED) PROVIDED BY OPERATING ACTIVITIES

 

 

(90,202)

 

 

82,868 

 

 

5,010 

 

 

 —

 

 

(2,324)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Acquisition of property and equipment excluding financed purchases

 

 

(729)

 

 

(4,962)

 

 

 —

 

 

 —

 

 

(5,691)

 

Proceeds from sale of property and equipment

 

 

 —

 

 

798 

 

 

 —

 

 

 —

 

 

798 

 

Increase (decrease) in intercompany advances

 

 

 —

 

 

(57,146)

 

 

 —

 

 

57,146 

 

 

 —

 

Change in restricted cash

 

 

 —

 

 

283 

 

 

(6)

 

 

 —

 

 

277 

 

NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES

 

 

(729)

 

 

(61,027)

 

 

(6)

 

 

57,146 

 

 

(4,616)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Proceeds from debt

 

 

280,200 

 

 

 —

 

 

 —

 

 

 —

 

 

280,200 

 

Repayment of debt

 

 

(252,748)

 

 

(9,364)

 

 

 —

 

 

 —

 

 

(262,112)

 

Issuance of common stock and effect of cashless exercise

 

 

(773)

 

 

 —

 

 

 —

 

 

 —

 

 

(773)

 

Increase (decrease) in intercompany advances

 

 

61,103 

 

 

 —

 

 

(3,957)

 

 

(57,146)

 

 

 —

 

NET CASH (USED) PROVIDED BY FINANCING ACTIVITIES

 

 

87,782 

 

 

(9,364)

 

 

(3,957)

 

 

(57,146)

 

 

17,315 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net (Decrease) Increase in Cash and Cash Equivalents

 

 

(3,149)

 

 

12,477 

 

 

1,047 

 

 

 —

 

 

10,375 

 

Cash and Cash Equivalents at Beginning of Year

 

 

75,087 

 

 

36,764 

 

 

23,732 

 

 

 —

 

 

135,583 

 

Cash and Cash Equivalents at End of Period

 

$

71,938 

 

$

49,241 

 

$

24,779 

 

$

 —

 

$

145,958 

 

 

 

27


 

Table of Contents

 

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

THREE MONTHS ENDED MARCH 31, 2014

(Unaudited-in thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Non-

 

 

 

 

 

 

 

 

 

Tutor Perini

 

Guarantor

 

Guarantor

 

 

 

 

Total

 

 

 

Corporation

 

Subsidiaries

 

Subsidiaries

 

Eliminations

 

Consolidated

 

Cash Flows from Operating Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income (loss)

 

$

15,939 

 

$

11,619 

 

$

3,662 

 

$

(15,281)

 

$

15,939 

 

Adjustments to reconcile net income to net cash from operating activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Depreciation and amortization

 

 

1,780 

 

 

12,947 

 

 

(68)

 

 

 —

 

 

14,659 

 

Equity in earnings of subsidiaries

 

 

(15,281)

 

 

 —

 

 

 —

 

 

15,281 

 

 

 —

 

Stock-based compensation expense

 

 

5,316 

 

 

113 

 

 

 —

 

 

 —

 

 

5,429 

 

Excess income tax benefit from stock-based compensation

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

Deferred income taxes

 

 

4,624 

 

 

(4,579)

 

 

 —

 

 

 —

 

 

45 

 

(Gain) loss on sale of property and equipment

 

 

427 

 

 

 —

 

 

 —

 

 

 —

 

 

427 

 

Other long-term liabilities

 

 

2,886 

 

 

608 

 

 

 —

 

 

 —

 

 

3,494 

 

Other non-cash items

 

 

855 

 

 

(1,282)

 

 

 —

 

 

 —

 

 

(427)

 

Changes in other components of working capital 

 

 

(48,652)

 

 

(37,991)

 

 

5,947 

 

 

 —

 

 

(80,696)

 

NET CASH PROVIDED (USED) BY OPERATING ACTIVITIES

 

 

(32,106)

 

 

(18,565)

 

 

9,541 

 

 

 —

 

 

(41,130)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Acquisition of property and equipment excluding financed purchases

 

 

(4,041)

 

 

(4,311)

 

 

 —

 

 

 —

 

 

(8,352)

 

Proceeds from sale of property and equipment

 

 

(427)

 

 

1,844 

 

 

 —

 

 

 —

 

 

1,417 

 

Change in restricted cash

 

 

15,465 

 

 

(664)

 

 

(15,476)

 

 

 —

 

 

(675)

 

NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES

 

 

10,997 

 

 

(3,131)

 

 

(15,476)

 

 

 —

 

 

(7,610)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Proceeds from debt

 

 

250,656 

 

 

(72,618)

 

 

 —

 

 

 —

 

 

178,038 

 

Repayment of debt

 

 

(179,032)

 

 

65,481 

 

 

 —

 

 

 —

 

 

(113,551)

 

Business acquisition related payments

 

 

 —

 

 

(1,031)

 

 

 —

 

 

 —

 

 

(1,031)

 

Excess income tax benefit from stock-based compensation

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

 —

 

Issuance of common stock and effect of cashless exercise

 

 

(1,575)

 

 

 —

 

 

 —

 

 

 —

 

 

(1,575)

 

Increase (decrease) in intercompany advances

 

 

(63,312)

 

 

60,771 

 

 

2,541 

 

 

 —

 

 

 —

 

NET CASH (USED) PROVIDED BY FINANCING ACTIVITIES

 

 

6,737 

 

 

52,603 

 

 

2,541 

 

 

 —

 

 

61,881 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net Increase (Decrease) in Cash and Cash Equivalents

 

 

(14,372)

 

 

30,907 

 

 

(3,394)

 

 

 —

 

 

13,141 

 

Cash and Cash Equivalents at Beginning of Year

 

 

88,995 

 

 

18,031 

 

 

12,897 

 

 

 —

 

 

119,923 

 

Cash and Cash Equivalents at End of Period

 

$

74,623 

 

$

48,938 

 

$

9,503 

 

$

 —

 

$

133,064 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

28


 

Table of Contents

 

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

 

The following discusses our financial position at March 31, 2015 and the results of our operations for March 31, 2015 and should be read in conjunction with: (1) the unaudited consolidated condensed financial statements and notes contained herein, and (2) the audited consolidated financial statements and accompanying notes to our Annual Report on Form 10-K for the fiscal year ended December 31, 2014.

 

Overview

 

We were incorporated in 1918 as a successor to businesses that had been engaged in providing construction services since 1894. We provide diversified general contracting, construction management and design-build services to private customers and public agencies throughout the world. Our construction business is conducted through three basic segments or operations: Civil, Building, and Specialty Contractors. Our Civil segment specializes in public works construction and the repair, replacement and reconstruction of infrastructure, including highways, bridges, mass transit systems and water and wastewater treatment facilities, primarily in the western, midwestern, northeastern, and mid-Atlantic regions of the United States. Our Building segment has significant experience providing services to a number of specialized building markets, including the hospitality and gaming, transportation, healthcare, municipal and commercial offices, sports and entertainment, educational, correctional facilities, biotech, pharmaceutical and high-tech markets. Our Specialty Contractors segment specializes in plumbing, HVAC, electrical, mechanical, and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming, and transportation end markets, among others.

 

The contracting and management services that we provide consist of general contracting, pre-construction planning and comprehensive management services, including planning and scheduling the manpower, equipment, materials and subcontractors required for the timely completion of a project in accordance with the terms and specifications contained in a construction contract. We also offer self-performed construction services including site work, concrete forming and placement, steel erection, electrical and mechanical, plumbing and HVAC. We provide these services by using traditional general contracting arrangements, such as fixed price, guaranteed maximum price and cost plus fee contracts and, to a lesser extent, construction management or design-build contracting arrangements. In the ordinary course of our business, we enter into arrangements with other contractors, referred to as “joint ventures,” for certain construction projects. Each of the joint venture participants is usually committed to supply a predetermined percentage of capital, as required, and to share in a predetermined percentage of the income or loss of the project. Generally, each joint venture participant is fully liable for the obligations of the joint venture.

 

We believe our leadership position as the contractor of choice for large, complex civil and building projects will support our long-term backlog growth. We continue to strategically focus on growing our business by pursuing and obtaining higher-margin public works projects and building projects on an opportunistic basis. In addition, we continue to leverage our unique, substantial self-performance and schedule control capabilities to obtain additional large-scale civil and building awards. We have capitalized on this leadership position and these synergies with various recent significant new awards and pending awards (see Backlog Analysis on page 30).

 

 

 

29


 

Table of Contents

 

The following tables set forth our consolidated condensed statement of operations:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Consolidated Results of Operations

 

 

 

 

 

 

 

% Change

 

 

 

 

Three Months Ended

 

 

Favorable

 

 

 

 

March 31,

 

 

(Unfavorable)

 

 

 

 

2015

 

 

2014

 

 

2015 vs. 2014

 

 

 

(In thousands)

 

 

 

 

Revenues

 

$

1,066,465 

 

$

955,233 

 

 

11.6% 

 

Cost of operations

 

 

975,706 

 

 

849,886 

 

 

(14.8)%

 

Gross profit

 

 

90,759 

 

 

105,347 

 

 

(13.8)%

 

General and administrative expenses

 

 

70,675 

 

 

63,850 

 

 

(10.7)%

 

Income from construction operations

 

 

20,084 

 

 

41,497 

 

 

(51.6)%

 

Other income (expense), net

 

 

(754)

 

 

(3,373)

 

 

77.6% 

 

Interest expense

 

 

(11,125)

 

 

(10,831)

 

 

(2.7)%

 

Income before income taxes

 

 

8,205 

 

 

27,293 

 

 

(69.9)%

 

Provision for income taxes

 

 

(3,079)

 

 

(11,354)

 

 

72.9% 

 

Net income (loss)

 

$

5,126 

 

$

15,939 

 

 

(67.8)%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Consolidated Results of Operations

 

 

Three Months Ended March 31,

 

 

 

2015

 

 

2014

 

 

 

 

 

(As a percentage of Revenues)

Revenues

 

 

100.0% 

 

 

100.0% 

 

 

Cost of operations

 

 

91.5% 

 

 

89.0% 

 

 

Gross profit

 

 

8.5% 

 

 

11.0% 

 

 

General and administrative expenses

 

 

6.6% 

 

 

6.7% 

 

 

Income from construction operations

 

 

1.9% 

 

 

4.3% 

 

 

Other income (expense), net

 

 

(0.1)%

 

 

(0.4)%

 

 

Interest expense

 

 

(1.0)%

 

 

(1.1)%

 

 

Income (loss) before income taxes

 

 

0.8% 

 

 

2.8% 

 

 

(Provision) benefit for income taxes

 

 

(0.3)%

 

 

(1.2)%

 

 

Net income (loss)

 

 

0.5% 

 

 

1.6% 

 

 

 

Revenues were $1,066.5 million for the three months ended March 31, 2015 compared to $955.2 million for the same period in 2014. Income from construction operations was $20.1 million for the three months ended March 31, 2015 compared to $41.5 million for the same period in 2014. Net income for the three months ended March 31, 2015 was $5.1 million compared to $15.9 million for the same period in 2014. Basic and diluted earnings per share were $0.11 and $0.10, respectively, for the three months ended March 31, 2015, compared to basic and diluted earnings per share of $0.33 for the same period in 2014.  

 

Revenues increased approximately $111 million for the three months ended March 31, 2015 compared to the same period in 2014 due primarily to increased activity on various smaller building projects in multiple states, an industrial project in California, certain mixed-use facility projects in multiple states, several large mass transit projects in New York, and bridge projects in the Midwest. The increase was partially offset by decreased activity on various smaller electrical projects in the southern U.S. and certain tunnel projects on the West Coast.

 

The decrease in net income for the three months ended March 31, 2015 compared to the same period in 2014 was due primarily to decreased activity on certain higher-margin projects that contributed significantly in the first quarter of 2014, but had a negligible contribution in the first quarter of 2015, and decreased activity on certain tunnel projects on the West Coast.

 

At March 31, 2015, working capital was  $1,143.3 million, an increase of $29.3 million from $1,114.0 million at December 31, 2014.

 

Backlog Analysis

 

During the first quarter of 2015, we booked various new awards and adjustments to existing contracts into backlog across each of our business segments, and ended the quarter with contract backlog of approximately $7.8 billion, consistent with the same level at December 31, 2014. Significant new awards included a $239 million hospitality building project, a $117 million mixed-use building project, and a $58 million highway improvement project, all in Pennsylvania; a  $56 million tunnel project in New York; and a $50 million educational building project in Mississippi.

30


 

Table of Contents

 

 

In addition to our existing backlog, we continue to have a significant volume of pending contract awards, including up to $2.3 billion in various future phases of the Hudson Yards project, approximately $1.3 billion for four building projects in California, and approximately $700 million in various other contracts. We anticipate booking many of these and other pending awards into backlog over the next several quarters. We continue tracking several large-scale civil and building prospects for both public and private sector customers as we further leverage our self-performance and schedule control capabilities.

 

The following table provides an analysis of our backlog by business segment for March 31, 2015:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Backlog at

 

New Business

 

Revenues

 

Backlog at

 

 

December 31, 2014

 

Awarded (1)

 

Recognized

 

March 31, 2015

 

 

 

(in millions)

Civil

 

$

3,563.2 

 

$

223.3 

 

$

(374.7)

 

$

3,411.8 

Building

 

 

2,187.8 

 

 

465.8 

 

 

(398.8)

 

 

2,254.8 

Specialty Contractors

 

 

2,080.7 

 

 

334.0 

 

 

(293.0)

 

 

2,121.7 

Total

 

$

7,831.7 

 

$

1,023.1 

 

$

(1,066.5)

 

$

7,788.3 

 


(1)

New business awarded consists of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

 

Critical Accounting Policies

 

Our significant accounting policies are described in Note 1 — Description of Business and Summary of Significant Accounting Policies of the Notes to Consolidated Financial Statements in Part IV, Item 15. Exhibits and Financial Statement Schedules, included in our Annual Report on Form 10-K for the fiscal year ended December 31, 2014. Our critical accounting policies are also identified and discussed in Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations of our Annual Report on Form 10-K for the fiscal year ended December 31, 2014.

 

Recently Issued Accounting Pronouncements

 

In May 2014, the Financial Accounting Standards Board (“FASB”) issued Accounting Standards Update (“ASU”) No. 2014-09, Revenue from Contracts with Customers (Topic 606), which supersedes the revenue recognition requirements in ASC 605, Revenue Recognition. This ASU addresses when an entity should recognize revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the entity expects to be entitled in exchange for those goods or services. This ASU is effective for annual reporting periods beginning after December 15, 2016, including interim periods within that reporting period, using one of two retrospective application methods. Early application is not permitted. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

 

In June 2014, the FASB issued ASU No. 2014-12, Compensation — Stock Compensation (Topic 718): Accounting for Share-Based Payments When the Terms of an Award Provide That a Performance Target Could Be Achieved after the Requisite Service Period, clarifying the recognition timing of expense associated with certain performance based stock awards when the performance target that affects vesting could be achieved after the requisite service period. This ASU is an update to FASB ASC Topic 718 and is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015 with earlier adoption permitted. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements.

 

In February 2015, the FASB issued ASU No. 2015-02, Consolidation (Topic 810). The goal of this ASU is to reduce the potentially distortive impact on reporting entities’ consolidated financial statements resulting from the consolidation of certain legal entities, including joint ventures and variable interest entities. This ASU is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The adoption of this guidance is not expected to have a material impact on the Company’s financial statements. 

In April 2015, the FASB issued ASU 2015-03, Interest – Imputation of Interest (Subtopic 835-30). This ASU requires that debt issuance costs related to a recognized debt liability be presented in the balance sheet as a direct deduction from the carrying amount of that debt liability, consistent with debt discounts. This ASU is effective for fiscal years, and interim periods within those years, beginning after December 15, 2015. The adoption of this ASU is not expected to have a material impact on the Company’s financial statements. 

31


 

Table of Contents

 

Use of and changes in estimates

 

The Company’s construction business involves making significant estimates and assumptions in the normal course of business relating to its contracts and its joint venture contracts. Management focuses on evaluating the performance of contracts individually. These estimates can vary in the normal course of business as projects progress, when estimated productivity assumptions change based on experience to date and uncertainties are resolved. Change orders and claims, as well as changes in related estimates of costs to complete, are considered revisions in estimates. The Company uses the cumulative catch-up method applicable to construction contract accounting to account for revisions in estimates. The impact on operating margin in a reporting period and future periods from a change in estimate will depend on the stage of contract completion.

 

There were no significant changes in contract estimates at completion that impacted gross profit for the three months ended March 31, 2015 and 2014. 

 

Results of Operations

 

Comparison of the Three Months Ended March 31, 2015 with the Three Months Ended March 31, 2014

 

Revenues

 

The following table summarizes our revenues by business segment with the prior year.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues for the

 

 

 

 

 

 

 

 

 

Three Months Ended March 31,

 

 

 

 

 

 

 

(dollars in millions)

 

2015

 

2014

 

$ Change

 

% Change

Civil

 

$

374.7 

 

$

365.2 

 

$

9.5 

 

 

2.6 

%

Building

 

 

398.8 

 

 

297.9 

 

 

100.9 

 

 

33.9 

%

Specialty Contractors

 

 

293.0 

 

 

292.1 

 

 

0.9 

 

 

0.3 

%

      Total

 

$

1,066.5 

 

$

955.2 

 

$

111.3 

 

 

11.7 

%

 

 

Civil Segment

 

Civil segment revenues increased  $9.5 million, or 2.6%, for the three months ended March 31, 2015, compared to the same period in 2014. The increase was due primarily to increased activity on several large mass transit projects in New York and on various bridge projects in the Midwest. The increase was partially offset by decreased activity on certain tunnel projects on the West Coast and on certain higher-margin projects.

 

Building Segment

 

Building segment revenues increased  $100.9 million, or 33.9%, for the three months ended March 31, 2015 compared to the same period in 2014. The increase was due primarily to increased activity on various smaller building projects in California, the southern U.S., and Florida, as well as on an industrial project in California, certain mixed-use facility projects in New York (including Hudson Yards), California, and Louisiana, and certain hospitality and gaming projects in Mississippi and Florida. The increase was partially offset by decreased activity on certain courthouse projects.

 

Specialty Contractors Segment

 

Specialty Contractors segment revenues increased  $0.9 million, or 0.3%, for the three months ended March 31, 2015 compared to the same period in 2014. The increase was due primarily to increased activity on various electrical and mechanical projects in New York. The increase was partially offset by decreased activity on various smaller electrical projects in the southern U.S., as well as on electrical projects at the World Trade Center and mechanical projects at the United Nations in New York.

 

32


 

Table of Contents

 

Income from Construction Operations

 

The following table summarizes our income from construction operations by business segment.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income from Construction Operations

 

 

 

 

 

 

 

 

 

 

 

 

 

 

and Operating Margins

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended March 31,

 

 

Change in

 

 

2015

 

2014

 

Amount

 

Margin

(dollars in millions)

 

Amount

 

 

Margin

 

Amount

 

 

Margin

 

$

 

 

%

 

%

Civil

 

$

30.6 

 

 

8.2 

%

 

$

44.4 

 

 

12.2 

%

 

$

(13.8)

 

 

(31.1)

%

 

(4.0)

%

Building

 

 

(2.3)

 

 

(0.6)

%

 

 

1.8 

 

 

0.6 

%

 

 

(4.1)

 

 

(227.8)

%

 

(1.2)

%

Specialty Contractors

 

 

10.5 

 

 

3.6 

%

 

 

7.8 

 

 

2.7 

%

 

 

2.7 

 

 

34.6 

%

 

0.9 

%

 

 

 

38.8 

 

 

3.6 

%

 

 

54.0 

 

 

5.7 

%

 

 

(15.2)

 

 

(28.1)

%

 

(2.1)

%

Corporate

 

 

(18.8)

 

 

(1.8)

%

 

 

(12.5)

 

 

(1.3)

%

 

 

(6.3)

 

 

(50.4)

%

 

(0.5)

%

Income from construction operations

 

$

20.0 

 

 

1.9 

%

 

$

41.5 

 

 

4.3 

%

 

$

(21.5)

 

 

(51.8)

%

 

(2.4)

%

 

Civil Segment

 

Civil segment income from construction operations decreased $13.8 million, or 31.1%, for the three months ended March 31, 2015 compared to the same period in 2014. The decrease was due primarily to the decreased activity discussed above under Revenues.  

 

Civil segment operating margin declined to 8.2% for the three months ended March 31, 2015, compared to 12.2% for the same period in 2014. The reduction in Civil segment operating margin was due primarily to the decreased activity discussed above under Revenues.

 

Building Segment

 

Building segment income from construction operations decreased  $4.1 million, or 227.8%, for the three months ended March 31, 2015 compared to the same period in 2014. The decrease was due primarily to an unfavorable adjustment to the estimated recovery for a certain office building project on the East Coast.

 

Building segment operating margin declined to -0.6% for the three months ended March 31, 2015, compared to 0.6% for the same period in 2014. The reduction in Building segment operating margin was due primarily to the unfavorable adjustment discussed above.

 

Specialty Contractors Segment

 

Specialty Contractors segment income from construction operations increased  $2.7 million, or 34.6% for the three months ended March 31, 2015 compared to the same period in 2014. The increase was due primarily to improved performance in certain business units, especially in our mechanical unit in New York and in our concrete placement unit.

 

Specialty Contractors segment operating margin increased to 3.6% for the three months ended March 31, 2015, compared to 2.7% for the same period in 2014 due primarily to the reasons discussed above.

 

Corporate

 

Corporate general and administrative expenses increased $6.3 million, or 50.4%, for the three months ended March 31, 2015 compared to the same period in 2014 due primarily to increased performance-based incentive compensation expense.

 

Consolidated Other Income, Interest Expense and Provision for Income Taxes

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(dollars in millions)

 

March 31, 2015

 

March 31, 2014

 

$ Change

 

% Change

Three Months Ended

 

 

 

 

 

 

 

 

 

 

 

 

Other income (expense), net

 

$

(0.8)

 

$

(3.4)

 

$

2.6 

 

 

(76.5)%

Interest expense

 

 

(11.1)

 

 

(10.8)

 

 

(0.3)

 

 

2.8% 

Provision for income taxes

 

 

(3.1)

 

 

(11.4)

 

 

8.3 

 

 

(72.8)%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

33


 

Table of Contents

 

Other expense net decreased $2.6 million for the three months ended March 31, 2015, compared to the same period in 2014. The decrease was due primarily to a reduction in expense recognized for changes in contingent consideration liabilities associated with historical acquisitions.

 

Interest expense increased $0.3 million for the three months ended March 31, 2015, compared to the same period in 2014.

 

Provision for income taxes was $3.1 million for the three months ended March 31, 2015, as compared to $11.4 million for the same period in 2014.  The effective income tax rate was 37.5% for March 31, 2015, compared to 41.6% for the same period in 2014. The decrease in the effective tax rate for March 31, 2015, compared to the same period in 2014, was primarily due to favorable discrete tax item adjustments related to the prior year tax positions.

 

Liquidity and Capital Resources

 

Cash and Working Capital

 

At March 31, 2015 and December 31, 2014, cash held by us and available for general corporate purposes was $61.9 million and $40.8 million, respectively. Our proportionate share of cash held by joint ventures and available only for joint venture-related uses, including distributions to joint venture partners, was $84.1 million and $94.7 million at March 31, 2015 and December 31, 2014, respectively, and our restricted cash was $44.1 million and $44.4 million at March 31, 2015 and December 31, 2014, respectively. We believe that our cash flows will be sufficient to satisfy our currently anticipated cash requirements through at least the next 12 months.

 

We do not believe that it is likely we will be called upon to contribute significant additional capital in the event of default by any of our partners. We require each partner in the joint ventures in which we participate to accept joint and several responsibility for all obligations of the joint venture. Prior to forming a joint venture, we conduct a thorough analysis of the prospective partner to determine its capabilities, specifically relating to construction expertise, track record for delivering a quality product on time, reputation in the industry, as well as financial strength and available liquidity. We utilize a number of resources to verify a potential joint venture partner’s financial condition, including credit rating reports and financial information contained in its audited financial statements. We specifically review a potential partner’s available liquidity and bonding capacity. In the event we are concerned with the financial viability of a potential partner, we will require substantial initial cash contributions upon inception of the joint venture to mitigate the risk that we would be required to cover a disproportionate share of the joint venture’s future cash needs.

 

The majority of our joint venture contracts are for various government agencies that typically require the joint venture and/or our partners to complete a thorough pre-qualification process. This pre-qualification process typically includes the verification of each partner’s financial condition and capacity to perform the work, as well as the issuance of performance bonds by surety companies who also independently verify each partner’s financial condition.

 

A summary of cash flows for each of the three months ended March 31, 2015 and 2014 is set forth below:

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended March 31,

 

(dollars in millions)

 

 

2015

 

 

2014

 

Cash flows from:

 

 

 

 

 

 

 

Operating activities

 

$

(2.3)

 

$

(41.1)

 

Investing activities

 

 

(4.6)

 

 

(7.6)

 

Financing activities

 

 

17.3 

 

 

61.9 

 

Net increase in cash

 

 

10.4 

 

 

13.2 

 

Cash at beginning of year

 

 

135.5 

 

 

119.9 

 

Cash at end of period

 

$

145.9 

 

$

133.1 

 

 

During the three months ended March 31, 2015, we used $2.3 million in cash from operating activities. In the first quarter of 2015 we received full and final payments related to settlements reached on the MGM City Center matter and on a separate more recently completed building project. Because of strong collections in December 2014, we were required to make substantial payments to subcontractors and other vendors early in the first quarter of 2015, and we funded significant working capital associated with several of our larger civil and building projects that are underway but are yet to reach certain billing milestones. Ten projects collectively required us to fund more than $90 million of cost during the first quarter of 2015. We used $4.6 million in cash from investing activities, due primarily to the acquisition of property and equipment of $5.7 million offset by the sale of property and construction equipment of $0.8 million. We received $17.3 million in cash from financing activities, due primarily to increased borrowings under our Credit Facility offset by cash used for scheduled debt repayments.

 

At March 31, 2015, we had working capital of $1,143.3 million, a ratio of current assets to current liabilities of 1.86, and a ratio of debt to equity of 0.64 compared to working capital of $1,114.0 million, a ratio of current assets to current liabilities of 1.82 and a ratio of debt to equity of 0.63 at December 31, 2014.

34


 

Table of Contents

 

Long-term Debt

 

Debt was $883.3 million at March 31, 2015, an increase of $17.9 million from $865.4 million at December 31, 2014,  due primarily to a net increase in borrowings of $55.0 million on the revolving line of credit offset by payments of $37.1 million on other debt. We utilized the revolving facility for outstanding letters of credit in the amount of $0.2 million. Accordingly, at March 31, 2015, we had $114.8 million available to borrow under our credit agreement. We believe that our financial position and credit arrangements are sufficient to support our current backlog and anticipated new work.

 

Excluding the outstanding borrowings of $185.0 million on our revolving line of credit, the unsecured senior notes of $298.8 million and our $238.8 million term loan (which had a first loan payment due on September 30, 2014), the remaining balance of $160.7 million of our outstanding debt is generally secured by the underlying assets. Our debt to equity ratio was 0.64 as of March 31, 2015 compared to 0.63 as of December 31, 2014.

 

On June 5, 2014, the Company entered into the Credit Facility, restructuring its former $300 million revolving credit facility and $200 million Term Loan. All outstanding amounts under the Fifth Amended and Restated Credit Agreement were repaid in full using proceeds of the Credit Facility. The new agreement provides for a $300 million revolving credit facility (the “Revolving Credit Facility) and a $250 million term loan (the “Term Loan”) with Bank of America, N.A. as administrative agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The Term Loan principal is to be repaid on a quarterly basis, with 6.0% of the original total outstanding principal repaid in year 1, 9.0% in year 2, 12.0% in year 3, 15.0% in year 4 and 13.5% in year 5 along with a balloon payment of the remaining 44.5%.  Borrowings under the Revolving Credit Facility will bear interest based either on Bank of America’s prime lending rate or the London Interbank Offered Rate (“LIBOR”) plus an applicable margin. Borrowings under the Term Loan bear interest based on LIBOR plus an applicable margin. Included in the Credit Facility is a special provision allowing an additional accordion provision, which the Company may opt to utilize at a future date to increase either the Revolving Credit Facility or establish one or more new term loan commitments, up to an aggregate amount not to exceed $300 million. The Credit Facility provides a sublimit for the issuance of letters of credit up to the aggregate amount of $150 million. Both the Revolving Credit Facility and the Term Loan are estimated to mature on June 5, 2019. 

 

As of the filing date of this Form 10-Q, we are in compliance and expect to continue to be in compliance with the financial covenants under the Credit Facility.

 

There were no other material changes in our contractual obligations during the three months ended March 31, 2015.

 

Off-Balance Sheet Arrangements

 

We do not have financial partnerships with unconsolidated entities, such as entities often referred to as structured finance or special purpose entities which are often established for the purpose of facilitating off-balance sheet arrangements or other contractually narrow or limited purposes, except that we participate in one variable interest entity. This entity does not have and is not reasonably likely to have a material current or future effect on our financial condition, changes in financial condition, revenues or expenses, results of operations, liquidity, capital expenditures or capital resources. Accordingly, we are not exposed to any financing, liquidity, market or credit risk that could arise from such relationships.

 

Forward-looking Statements

 

The statements contained in this Management’s Discussion and Analysis of the Consolidated Condensed Financial Statements on Form 10-Q that are not purely historical are forward-looking statements within the meaning of Section 27A of the Securities Act of 1933 and Section 21E of the Securities Exchange Act of 1934, including without limitation, statements regarding our management’s expectations, hopes, beliefs, intentions or strategies regarding the future. These forward-looking statements are based on our current expectations and beliefs concerning future developments and their potential effects on us. Our expectations, beliefs and projections are expressed in good faith and we believe there is a reasonable basis for them. There can be no assurance that future developments affecting us will be those that we have anticipated. These forward-looking statements involve a number of risks, uncertainties (some of which are beyond our control) or other assumptions that may cause actual results or performance to be materially different from those expressed or implied by such forward-looking statements. These risks and uncertainties include, but are not limited to:

 

·

our ability to win new contracts and convert backlog into revenue;

·

our ability to successfully and timely complete construction projects;

·

our ability to realize the anticipated economic and business benefits of our acquisitions and our strategy to assemble and operate a Specialty Contractors business segment;

·

the potential delay, suspension, termination or reduction in scope of a construction project;

·

the continuing validity of the underlying assumptions and estimates of total forecasted project revenues, costs and profits and project schedules;

·

the outcomes of pending or future litigation, arbitration or other dispute resolution proceedings;

·

the availability of borrowed funds on terms acceptable to us;

35


 

Table of Contents

 

·

the ability to retain certain members of management;

·

the ability to obtain surety bonds to secure our performance under certain construction contracts;

·

possible labor disputes or work stoppages within the construction industry;

·

changes in federal and state appropriations for infrastructure projects and the impact of changing economic conditions on federal, state and local funding for infrastructure projects;

·

possible changes or developments in international or domestic political, social, economic, business, industry, market and regulatory conditions or circumstances;

·

actions taken or not taken by third parties including our customers, suppliers, business partners, and competitors and legislative, regulatory, judicial and other governmental authorities and officials; and

·

other risks and uncertainties discussed under the heading “Risk Factors” in our Annual Report on Form 10-K for the year ended December 31, 2014 filed with the Securities and Exchange Commission on February 26, 2015.

 

We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.

 

Item 3. Quantitative and Qualitative Disclosures About Market Risk

 

There has been no material change in our exposure to market risk from that described in Item 7A of our Annual Report on Form 10-K for the year ended December 31, 2014, filed with the Securities and Exchange Commission on February 26, 2015.

 

Item 4. Controls and Procedures

 

Disclosure Controls and Procedures

 

The Company’s management, including our Chief Executive Officer and Chief Financial Officer, has carried out an evaluation of the effectiveness of the design and operation of our disclosure controls and procedures as required by Rule 13a-15(b) under the Securities Exchange Act of 1934, as amended (“Exchange Act”) as of the period covered by this report. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that the Company’s disclosure controls and procedures (a) were effective to ensure that information we are required to disclose in reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in Securities and Exchange Commission rules and forms and (b) include, without limitation, controls and procedures designed to ensure that information required to be disclosed by us in reports filed or submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.

 

Changes in Internal Controls Over Financial Reporting

 

There were no changes in our internal control over financial reporting during the period covered by this report that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

 

Part II. - Other Information

 

Item 1. Legal Proceedings

 

From time to time in the ordinary course of business, we are subject to claims, asserted or unasserted, or named as a party to lawsuits or investigations. Litigation can be expensive and disruptive to normal business operations. Moreover, the results of legal proceedings cannot be predicted with any certainty and, in the case of more complex legal proceedings, the results are difficult to predict at all. We disclosed information about certain of our legal proceedings in Part I, Item 3 of our Annual Report on Form 10-K for the year ended December 31, 2014. For an update to those disclosures, see Note 7 — Contingencies and Commitments to Consolidated Condensed Financial Statements.

 

Item 1A. Risk Factors

 

Information regarding risk factors affecting our business is discussed in our Annual Report on Form 10-K for the year ended December 31, 2014. There have been no material changes from those risk factors during the three months ended March 31, 2015.

 

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

 

None.

 

Item 3. Defaults Upon Senior Securities

 

None.

36


 

Table of Contents

 

 

Item 4. Mine Safety Disclosures

 

Section 1503 of the Dodd-Frank Wall Street Reform and Consumer Protection Act (the “Dodd-Frank Act”) requires domestic mine operators to disclose violations and orders issued under the Federal Mine Safety and Health Act of 1977 (the “Mine Act”) by the federal Mine Safety and Health Administration. We do not act as the owner of any mines but we may act as a mining operator as defined under the Mine Act where we may be an independent contractor performing services or construction of such mine.

 

Information concerning mine safety violations or other regulatory matters required by Section 1503(a) of the Dodd-Frank Act and Item 104 Regulation S-K is included in Exhibit 95.

 

 

Item 5. Other Information

 

None.

 

37


 

Table of Contents

 

Item 6. Exhibits

 

 

 

 

 

 

 

Exhibit 3.     Articles of Incorporation and By-laws

 

3.1

Restated Articles of Organization (incorporated by reference to Exhibit 4 to Form S-2 (File No. 33-28401) filed on April 28, 1989).

 

3.2

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.2 to Form S-1 (File No. 333-111338) filed on December 19, 2003).

 

3.3

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on April 12, 2000).

 

3.4

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on September 11, 2008).

 

3.5

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.5 to Form 10-Q filed on August 10, 2009).

 

3.6

Second Amended and Restated By-laws of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on November 24, 2009).

 

 

 

Exhibit 31.1

Certification of Principal Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 31.2

Certification of Principal Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 32.1

Certification of Principal Executive Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 32.2

Certification of Principal Financial Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.

 

 

Exhibit 95

Mine Safety Disclosure — filed herewith.

 

 

Exhibit 101.INS

XBRL Instance Document.

Exhibit 101.SCH

XBRL Taxonomy Extension Schema Document.

Exhibit 101.CAL

XBRL Taxonomy Extension Calculation Linkbase Document.

Exhibit 101.LAB

XBRL Taxonomy Extension Label Linkbase Document.

Exhibit 101.PRE

XBRL Taxonomy Extension Presentation Linkbase Document.

Exhibit 101.DEF

XBRL Taxonomy Extension Definition Linkbase Document.

 

 

38


 

Table of Contents

 

SIGNATURES

 

Pursuant to the requirements of the Securities Exchange Act of 1934, as amended, the registrant has duly caused this report to be signed on its behalf by the undersigned hereunto duly authorized.

 

 

 

 

Tutor Perini Corporation

 

Registrant

 

 

 

 

Date: May 7, 2015

/s/Michael J. Kershaw

 

Michael J. Kershaw,

 

Executive Vice President and Chief Financial Officer

 

Duly Authorized Officer and Principal Financial Officer

 

 

 

 

39